R-79-99 Approving Village Participation in Non-tif Building and Site Grant ProgramVILLAGE OF LEMONT
RESOLUTION NO. g-
DATE /e -A5 -99
GRANT A RESOLUTION APPROVING VILLAGE PARTICIPATION IN NON -
TIF BUILDING AND SITE GRANT PROGRAM
WHEREAS, the Village of Lemont has adopted Ordinance 0- 72 -99, the Non -Tif Building
& Site Improvement Grant, Sign Grant and Low Interest Loan Programs, to provide
incentives for building reinvestment within the Village of Lemont's Non -Tif District; and
WHEREAS, in accordance with the Non -Tif Building & Site Improvement Grant, the
Village Board of Trustees shall consider participation in building reinvestment; and
WHEREAS, Ronald A. Nagel, as the property owner for the property known as 182
Wend Street, has completed the Non -Tif Building & Site Improvement Grant application
for Village participation of said property; and
WHEREAS, Village Staff has reviewed the 182 Wend Street application for compliance
with the Non -Tif Building & Site Improvement Grant guidelines and has recommended
approval of the request.
NOW, THEREFORE, BE IT RESOLVED, that the Village President is authorized to
execute the Building & Site Grant Agreement attached for Three Thousand Six Hundred
Forty Dollars ($3,640.00) in accordance with the terms of the Non -Tif Building & Site
Improvement guidelines.
PASSED AND APPROVED BY THE PRESIDENT AND BOARD OF TRUSTEES
OF THE VILLAGE OF LEMONT, COUNTIES OF COOK, DuPAGE AND WILL,
ILLINOIS, on this ds ^'day of . ,1999.
John Benik
Debby Blatzer
Keith Latz
Connie Markiewicz
Rick Rimbo
Mary Studebaker
Approved by me this of day of
Attest:
AYES NAYS PASSED ABSENT
P/'
C , ' ENE SMOLLEN, Village Clerk
,1.
RI a, ' D A WASNESKI, Village President
1999.
CHARLENE SMOLLEN, Village Clerk
APPROVED AS TO FORM:
Village Attorne
VILLAGE OF LEMONT
BUILDING AND SITE IMPROVEMENT GRANT PROGRAM
AGREEMENT
NON -TIF DISTRICT
THIS AGREEMENT, entered into this '7 7-.1 day of S re r , 761, between the
Village of Lemont, Illinois (hereinafter referred to as the "Village ") and the following
designated OWNER/LESSEE, to wit:
Owner's/Lessee's Name: a., 4t 4. )
Address: /
City: State: Zip Code: , D (i 3 9
Name of Business: L.) 4 jt-n b ado 542 el) I L., a)tJ
Project Address(es)
/
WITNESSETH
Whereas, the VILLAGE has established a Building & Site Improvement Grant Program for
application within designated commercial areas outside of the VILLAGE Tax Increment
Financing District; and
Whereas, said Building & Site Improvement Grant Program is administered by the
VILLAGE and is funded from General Revenues for purposes of control and prevention of
blight, dilapidation and deterioration of designated areas within the Village, and
Whereas, pursuant to said Program the VILLAGE has agreed to participate, subject to its
sole discretion, in sharing the cost of Building & Site Improvements to commercial
establishments within the District up to a maximum of one -half (1/2) of the approved
contract cost of such improvement but in no event shall the total Village participation
exceed Ten Thousand Seven Hundred Fifty Dollars($10,750.00) for construction and
architectural cost with $750.00 of that amount reserved for sign improvements only.
Architectural fees shall be limited to a One Thousand Dollars ($1,000.00) reimbursement;
and
Whereas, the OWNER's/LESSEE's property is located within the commercial area of the
Village, and the OWNER/LESSEE desires to participate in the Building and Site
Improvement Grant Program pursuant to the terms and provisions of this agreement.
NOW, THEREFORE, in consideration of the mutual covenants and agreement obtained
herein, the VILLAGE and OWNER/LESSEE do hereby agree as follows:
SECTION 1: COST SHARING - The VILLAGE shall share in the building and site
improvement cost and architect fee cost for the OWNER's/LESSEE's property up to fifty
percent (50 %), up to a maximum amount not exceeding Ten Thousand Seven Hundred
Fifty Dollars ($10,750.00) for construction and architectural cost with $750.00 reserved
for sign improvements. Architectural reimbursement shall be One Thousand Dollars
($1,000.00) . The actual amount per this agreement shall not exceed $ 3 �6YO, Dfor
construction cost and $ for architect fees. The building and site improvement
2
/historic preservation costs which are eligible for VILLAGE participation include all labor,
materials, equipment and other contract items necessary for the proper execution and
completion of the work as designated from the design drawings approved by the
VILLAGE. Said design drawings and specifications are attached hereto as Exhibit IV.
SECTION 2: DESIGN APPROVAL - No building and site improvement or historic
preservation work shall be undertaken until the design therefore has been submitted to and
approved by the Village. Following approval, the OWNER/LESSEE shall contract for the
work and shall commence and complete all such work within one hundred eighty (180) days
from the date of such approval.
SECTION 3: REVIEW OF PROJECT - The Economic Development Coordinator shall
periodically review the progress of the contractor's work on the building and site
improvement and historic preservation pursuant to this Agreement. Such inspections shall
not replace any required permit inspection by Village Inspectors. All work which is not in
conformance with the approved drawings and specifications shall be immediately remedied
by the OWNER/LESSEE and deficient or improper work shall be replaced and made to
comply with the approved drawings, specifications, and terms of this Agreement.
SECTION 4: DOCUMENTATION REQUIREMENTS - Upon completion of the
building and site improvement/historic preservation and upon its final inspection and
approval by the Building Department, the OWNER/LESSEE shall submit to the VILLAGE
a properly executed and notarized contractor statement and architect fee statement showing
the full cost of the work as well as each separate component amount due to the contractor
and each and every subcontractor involved in furnishing labor, materials, or equipment in
the work. In addition, the OWNER/LESSEE shall submit to the VILLAGE proof of
payment of the contract cost pursuant to the contractor's and architect's statements. The
VILLAGE shall, within thirty (30) days of receipt of the contractor's statement and proof
3
of payment issue a check to the OWNER/LESSEE in payment of: one -half of the approved
cost or Ten Thousand Seven Hundred Fifty Dollars ($10,750.00) whichever is less. In no
case shall the amount paid to the OWNER/LESSEE exceed the amount specified in this
Agreement or in the contractor's or architect's statements. At the time of reimbursement
and throughout the term of this agreement, the land use and signage under the control of
the OWNER/LESSEE shall be in conformance with zoning and sign code provisions.
SECTION 5: FAILURE TO COMPLETE WORK - If the OWNER/LESSEE or his
contractor fail to complete the building and site improvement/historic preservation work
provided for herein in conformity with the plans, specifications and all terms of this
Agreement, the Agreement shall terminate and the financial obligation on the part of the
VILLAGE shall cease and become null and void.
SECTION 6: ELIGIBLE IMPROVEMENT WORK - Installation, repair and
replacement of exit doors and hardware; repair, replacement or addition of exterior shutters
and awnings/canopies; repair, replacements or purchase of signs when done as part of an
overall building and site improvement grant; repair and replacement or installation of
exterior stairs, porches, railings and exit facilities; repair and rebuilding of exterior walls,
including cleaning, sealing, tuck pointing and painting; repair of window frames, sills,
glazing, replacement of glass and installation of new windows; installation of landscaping
such as stone or brick planters; paving for existing parking lots, lighting & striping (does
not apply to new parking lots or expansion of existing parking lots); replacing or upgrading
of stormwater, curbing, replacement of retaining walls, electrical wiring upgrades, interior
sprinkler systems, fire alarm systems, elevators, interior floor, ceiling improvements,
plumbing and improvements to meet ADA requirements.
SECTION 7: FILING OF LIEN/MAINTENANCE OF IMPROVEMENT - Upon
completion of the building and site improvement work pursuant to this Agreement and for a
4
period of three (3) years thereafter, the OWNER/LESSEE shall be responsible for properly
maintaining such building and site improvement/historic preservation in its finished form and
without change or alteration thereto, as provided in this Agreement, and for the said period
of three (3) years following completion of the construction thereof, the OWNER/LESSEE
shall not enter into any Agreement or contract or take any other steps to alter, change or
remove such improvement, or the approved design thereof, nor shall OWNER/LESSEE
undertake any other changes, by contract or otherwise, to the improvement provided for in
this Agreement unless such changes are first submitted to the Economic Development
Coordinator, and any additional review body or commission for approval; which approval
shall not be unreasonably withheld if the proposed changes do not substantially alter the
original design concept of the building and site improvements as specified in the drawings
and plans approved pursuant to this Agreement. In addition to this section, a lien on the
OWNER/LESSEE property shall be filed prior to the final payout of the program
reimbursement.
SECTION 8: UNRELATED IMPROVEMENTS - Nothing herein is intended to limit,
restrict or prohibit the OWNER/LESSEE from undertaking any other work in or about the
subject premises which is unrelated to the building and site improvement provided for in this
Agreement.
SECTION 9: AGREEMENT APPLICABLE TO FUTURE OWNERS - This
Agreement shall be binding upon the VILLAGE OF LEMONT and upon the
OWNER/LESSEE and its successors, to said property for a period of three (3) years from
and after the date of completion and approval of the facade improvement provided for
herein. It shall be the responsibility of the OWNER/LESSEE to inform subsequent
OWNER(s)/LESSEE(s) of Section 7 of this Agreement.
5
SECTION 10: MAXIMUM GRANT AWARDS - Nothing in this Agreement shall
prohibit a business or property owner from applying for more than one Grant. However, a
Ten Thousand Seven Hundred Fifty Dollars ($10,750.00) total limitation shall apply to all
Sign Grants, Building and Site Grants or Interest Rate Program Awards made to a single
building and/or lot within any three (3) year period. For the purpose of calculating the three
(3) year period, the date of the last Village payment shall be considered the start of the three
(3) year period. No grant may be utilized for the same or similar building contract work,
within a ten (10) year period of the last Village payment.
SECTION 11: VILLAGE INDEMNIFICATION REGARDING CONSTRUCTION
The owners of the subject property agree to defend and hold harmless the Village from any
and all claims which may arise out of said owners' construction activities under this
Agreement.
SECTION 12: GENERAL INDEMNIFICATION - In the event that, as a result of this
Agreement, or actions taken as required hereunder, the Village is made a party defendant in
any litigation arising by reason of this Agreement, and development activities contemplated
hereunder, the owners agree to defend and hold harmless the Village, the mayor, trustees,
officers and agents thereof, individually and collectively, from any suits and from any
claims, demands, setoff or other action including but not limited to judgments arising
therefrom. The obligation of the owners hereunder shall include and extend to payment of
reasonable attorneys' fees for the representation of the Village and its said officers and
agents in such litigation and includes expenses, court costs and fees; it being understood
that the owners where there shall be no applicable standards provided therein, shall have the
right to employ all such attorneys to represent the Village and its officers and agents in such
litigation, subject to the approval of the corporate authorities of the Village, which approval
shall not be unreasonably withheld. The owners shall have the right to appeal to courts of
6
appellate jurisdiction any judgment taken against the Village or its officers or agents in this
respect, and the Village shall join in any such appeal taken by the owners.
SECTION 13: PERFORMANCE OF AGREEMENT, - It is agreed that the parties
hereto may in law or in equity, by suit, action, mandamus, or any other proceeding,
including specific performance, enforce or compel the performance of this Agreement,
which shall include the right of the parties to recover a judgment for monetary damages
against each other, provided, however, that the owners shall not have a right to recover a
judgment for monetary damages against any elected or appointed official of the Village for
any breach of any of the terms of this Agreement. The Village reserves the right to maintain
an action to recover damages or any sums which owners have agreed to pay pursuant to
this Agreement and which have become due and remained unpaid.
SECTION 14: EXHIBITS - It is agreed that Exhibits I through VII shall be considered
part of this agreement.
SECTION 15: DISPLAY OF VILLAGE FUNDING PROMOTIONAL MATERIAL
All program participants shall be required to prominently display a poster identifying the
property as receiving Village funding. The sign will be provided by the Village and shall be
displayed from the date the Application is approved, to no less than thirty (30) days after
final approval and reimbursement is made.
SECTION 16: GUARANTEE OF FUNDS - The filing of an application for Building and
Site Improvement Grant in no way is a guarantee of funding by the Village of Lemont.
7
IN WITNESS THEREOF, the parties hereto have executed this Agreement on the date
first appearing above.
OWNERS/LESEEj
Program Participant
Date: SeV 7 9 �! jg 9
Property Owner
Date: 560 y
Form Rev. 7/99
8
Village President
Date: /o %
ATTEST:
Village Clerk
Date: /0 - v2 `� - ��
EXIIIBIT I
EXHIBITS
PROOF OF OWNERSHIP IN FORM OF DEED OR
TITLE INSURANCE POLICY (TAX BILL IS NOT
ACCEPTABLE).
E510M+Pi4 I IF LLA3FfNG THE PROPERTY, AN EXECUTED
VI NI
VI
Fftstpitgelterrorrr 4.
EXHIBIT III COPY OF APPLICATION
EXHIBIT IV RENOVATION PLANS
EXHIBIT V CONTRACTOR'S AGREEMENT
EXHIBIT VII
• IV w
SAMPLE LIEN SIGNED AND NOTORIZED.
9
h 'By: "'LEMONT NATL BANK; 6302577950;
O 2092, TTI (9-83) American Land Title Assr tion Lenders Policy 1970
i.ENDERS POLICY
simarlommlolummeleiiimeer
Policy Number 00258689
DWNERS
_ENDERS
1. Name of Insured:
LEMONT NATIONAL BANK
Amount of Insurance
Sep -9 -99 9:52AM;
EXHIBIT I
Schedule A
Date of Policy
JUNE 21, 1990
2. The estate or interest referred to herein is at Date of Policy vested in:
RONALD NAGEL AND MAURE;N NAGEL AS JOINT TENANTS
3 The estate or interest in the land described in this Schedule and which is encumbered by the insured mortgage is:
FEE SIMPLE
4. The mortgage, herein referred to as the insured mortgage, and the assignments thereof, if any, are described as follows;
A mortgage to secure an indebtedness of the amount stated herein.
Mortgagor; RONALD NAGEL AND MAUREEN NAGEL, HIS WIFE
Mortgagee: LEMONT NATIONAL BANK
Dated : NNE 8, 1990
Amount
Recorded : JUNE 21 , 1990
Document : 90,294,018
5. The and referred to in this policy is located in the County of
State of ILLINOIS and described as follows:
COOK
THE WEST 14.5 FEET OF THE EAST 468 FEET (EXCEPT THE SOUTH 372.50 FEET) OF THE
SOUTH 1/2 OF THE SOUTH 1/2 OF THE SOUTHWEST 1/4 OF SECTION 29, TOWNSHIP 37
NORTH, RANGE 11 EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS.
This policy valid only if Schedule B Is attached.
it By: LEMONT NATL. BANK;
TO 2083 PNTI (11-77)
ALTA LENDERS FORM
Policy Number 0C25b6bY
6302577950; Sep -9 -99 9:53AM; Page 3/4
Schedule B
This policy does not insure against loss or damage by reason of the following:
(1) Taxes
Permanent Tax Number: 22 -29. 309 -029 Volume: 062
General taxes for the years 1989 1989 and 1990.
General taxes for the year 1990 are not yet due or payable.
Estimated first installment 1989 taxes are paid.
Second installment 1989 taxes the August 30, 1990 and delinquent thereafter.
2. An easement for the purposes stated herein.
For A SANITARY SEWER
Recorded: FEBRUARY 28, 1986
Document: 86 -081 -020
Affects : THE EAST 10 FEET OF THE NORTH 164 FEET OF PIQ
3. An easement for the purposes stated herein.
In favor of COMMONWEALTH EDISON COMPANY
For : PUBLIC UTILITIES
Recorded : DECEMBER 12, 1986
Document : 86-597 -157
Affects : THE WEST 10 FEET OF THE EAST 58.00 FEET, OF THE NORTH 25 FEET,
OF THE SOUTH 162.50 FEET, AND ALSO; THE NORTH 10 FEET OF THE SOUTH 137.50
FEET, OF THE EAST 58.00 FEET, AND ALSO; THE EAST 10.00 FEET OF THE SOUTH
127.50 FEET, AND ALSO; THE SOUTH 10.00 FEET OF THE WEST 135.00 FEET OF
PREMISES IN QUESTION.
4. SUBJECT TO SEWER LINE EASEMENTS AS DISCLOSED BY CASE NUMBERS 80 011 8891 AND
81 CH 19525.
5. Rights of way for drainage ditches, tiles, feeders and laterals, if any.
6. NOTICE OF REQUIREMENTS FOR STORM WATER DETENTION AS RECORDED DECEMBER 17,
1980 AS DOCUMENT 25,709,393.
.
It By: LEMONT NATL BANK; 6302577950; Sep -9 -99 9:53AM; Page 4/4
TO 2085 PNTI (5.89)
ALTA LENDERS FORM SCHEDULE B CONTINUED
Policy Number
00258689
7. An easement for the purposes stated herein.
For STORM AND SANITARY SEWER
Recorded: DECEMBER 10, 1981
Document: 26,082,022
Affects : EAST 10 FEET OF THE NORTH 164.00 FELT OF PREMISES IN QUESTION AND
OTHER PROPERTY
13. An encroachment, as disclosed by a survey, of improvements located on the land,
onto land adjacent.
Location . WEST AND EAST LOT LINES
Consisting of: ASPHALT BY 0.6' WEST AND ASPHALT BY 1.0' EAST
9. An encroachment, as disclosed by a survey, of improvements located on the land
onto the easement shown as:
Exception No.: 2 AND 7
Consisting of ASPHALT BY 10 FEET EAST AND BUILDING BY 1 FOOT MORE OR LESS EAST
10. An encroachment, as disclosed by a survey, of improvements located on the land
onto the easement shown as:
Exception No.: 3
Consisting of: ASPHALT BY VARING AMOUNTS
11. Existing unrecorded leases, if any.
12. Rights of parties in possession under unrecorded leases, if any.
13. Assignment of Rents.
Assignor: RONALD NAG ;L AND MAUREEN NAGEL, HIS WIFE
Assignee: THE LEMONT NATIONAL BANK
Recorded: JUNE 21, 1990
Document: 90,294,019
Project Address(es
Building Owner:
Store /Company Name:
Name of Tenant:
Applicant Name:
File Number:
VILLAGE OF LEMONT
BUILDING & SITE IMPROVEMENT
GRANT PROGRAM
NON -TIF
APPLICATION
2 G.)C�
( �) ,� r-c"„�n.,o
EXHIBIT III
z (30, Year Purchased: / 8"5-
5 G2 ,ti.' � I Ma-
Lease Expiration Date:
Applicant Name: ,v 4
Applicant Business Address: / E'), 5
Applicant Business Phone: 25-11-5-6 7 6) Home Phone: '2,5 5J-5'13
Applicant(s): Building Owner: AA..n !JA c>c�- Tenant:
Number of Store Fronts:
Total Anticipated Budget:
Total Anticipated Grant Request:
,) N c
$ 7a8O,
$ 3,yo,1"
Description of Proposed Improvements:*
S �'r} -�. CO 41 A AAA.
3 OOc'
J 3 o <L
71-14c. '�7)Z 8 a
* Attach elevations of proposed improvements (if available)
PICTURE OF STORE FRONT:
Applicant Name:
File Number:
Applicant Name:
File Number:
BUDGET
(anticipated)
ACTIVITY
I
ESTIMATED COST
C)c Teg to".. e4,..)T1)0(,_
..4,,45iituic.,4.1c.,
42..7 ,For (?.9
Nct---) du.) wooc,--s
1
A3000, -'--u
I N
1 Cr 0 `r
sCa7-.4
- CV If 3 PUZA4 t
C-
1'9S
1
Total Anticipated Grant Request: $
Architect for the Project:
Name:
Address:
Phone:
N� A
Contractor for the Project:
7 (2)pGis-440
Name:
Address:
Phone:
(,3 — ? ;9 -5''39
Application will be reviewed by the Economic Development Coordinator , Building
Department, and Community Development Director.
Applicant Name: ad 4 rJ •ii1.4
File Number:
I, 120,-)4L-77 , hereby make application to the Village of Lemont for
a Building & Site Improvement Grant Program in the anticipated amount of
$ .1 understand that my application must be approved by the
Village and that it must conform to established design guidelines, as well as, specific design
recommendations of the Village of Lemont. I have read a copy of the Building & Site
Improvement Grant Program Agreement and lien provisions. If approved, I understand that
all work performed is subject to development, building, permit, and agreement provisions.
Applicant Signature
Date
Building Owner Date
Please return the completed application to:
Economic Development Coordinator
Village of Lemont
418 Main Street
Lemont, IL 60439
91 Mr
If you need assistance with the application and/or have general inquiries, please contact the
Economic Development Coordinator at (630) 257 -6440.
Sep -02 -99 04:26P
BENOIT Painting and Decorating
WOMAN BUSINESS ENTERPRISE
A Full Service Contractor
— EXHIBIT IV
13310 Archer Avenue • Lemont, IL 60439 • (708) 257 -5855
FAX (708) 257 -5860
Sept 1, 1999
Waterford Video
186 W. Wend Street
Lemont 11. 60439
We herewith submit the following proposal for
painting work on the exterior building at the above
mentioned address.
1: Front exterior: Wood fascia, two finish coats.
Brick around and below windows,
one coat filler and two finish coats.
Brick, one coat filler and two finish
coats.
2: North side:
3: South side:
Brick, one coat filler and two finish
coats.
4: Back of building: Concrete block, two finish coats.
5: Five metal doors, exterior side only. Color to be same
as walls.
6: One overhead door, exterior only. Color to be same as
walls.
7: Paint material we recommend is Acrylic Latex.
Manufacturer PPG or equal.
8: Total price of project: $2,390.00.
9: If we do caulking at cracks: add $100.00.
Note: If you wish us to power wash area to be painted
add: $490.00. We would recommend this.
inting
n Benoit
timator \Project Manager
Fully Insured and Bonripri
Proposal
Page No.
of EXHIBIT V
NORTHWEST AWNING CO.
Awnings • Doors • Windows
strikes. accidents or delays beyond our control. Owner to carry fire, tornado and other necessary insurance. Our
workers are fully covered by Workman's Compensation Insurance.
Note: This ptoposal may be
withdrawn by us if not accepted within
days.
=Flame of Proposal - The above prices, specifications
and conditions are satisfactory and are hereby accepted. You are authorized
to do the work as specified. Payment will be made as outlined above.
Signature
Date of Acceptance Signature
���'." I ='��� i" 416 W. Talcott Rd.• Park Ridge, IL 60068 -5409
!diulllit
d !'- - Office: 847 - 823 -6965 Fax: 847 - 823 -6015
F NL
AWNINGS DOORS WINDOWS
Canvas - Aluminum Prime - Steel Replacement Storm Windows - Vinyl Replacement
Canopies - Retractable Wrought Iron Security Double Hung - Casement
Complete take down, Storm Doors - Jalousie Bays /Bows - Garden
ye -hang & storage Professionally Installed Professionally Installed
ROPOSAL SUBMITTED TO i i
PHONE /° q Y'1 a( 7_ 7
ATE n 7q
MEET
1 R� r � ^ // ,('j-
�C�
JOB NAME
TY, STATE and ZIP CODE r
JOB LOCATION
3CHITECT
DATE OF PLANS
JOB PHONE
We hereby submit specifications
0
and estimates for:
(.
g
I ...
, AJ2-c.6-\)4_Aita,
ggr,,4_ .
of
cev,„.,--a„ 4 11, , , I
P 1 l
. lt,u—
i II 1 '
1
(„),,,/...
1
?/.5766
..... ..... .............
e Prop° e hereby to furnish mater al and abor — complete in accordance with above specifications, for the sum of:
O
dollars ($ V O )
•ayment to a e as follows: 0° V aj ( 0
0
I
a IC .�
- 000 °—°' `/ llr' 1��..�.-.
_
All material is guaranteed to be as specified. Al work to be completed in a workmanlike manner according to
Authorized
standard practices. Any alteration or deviation from above specifications involving extra costs will b_ executed only I £T•)-}#-
strikes. accidents or delays beyond our control. Owner to carry fire, tornado and other necessary insurance. Our
workers are fully covered by Workman's Compensation Insurance.
Note: This ptoposal may be
withdrawn by us if not accepted within
days.
=Flame of Proposal - The above prices, specifications
and conditions are satisfactory and are hereby accepted. You are authorized
to do the work as specified. Payment will be made as outlined above.
Signature
Date of Acceptance Signature
SEP. 03 99 (FRI) 10:33 CRAFTS TECHNOLOGY INC
ESTIMATE
847 758 0162 PAGE. 1/1
-da 7 ^b (a7
S41O SEAL COITINR
N4 Nurtw $Ilut
Limon IL 10451
130451.0
ESTIMA1 PIWAIWP FQR
Name: Waterford Video / Cameo Interiors
Address: _ 186 W. Wend / 182 W. Wend Street
Phone: 630-257-7898 / 257-5678
If paying by check, please make payable to Victor Fischer
ITEMIZEDISIIMAIE
ESTIMATE/INVOICE $
Seal Coat A ximatel Scare Feet / 3 d 0 .
l . Blow off entire rkin area both side drives and corn lete back lot.
2. Fill cracks with crack filler.
3. Seal Both side drives and front kin lot,
4. Area behind buildin to be sealed after re it by ComEd or seat tch after repair is made.
Both side drives and front rkin.. area to be sealed at earliest date weather
rmittin
on a Saturda ni _ t
with the frontparking area to be sealed after 10:00 p.m., (close of business hours). Side drives to be sealed
after 8 :00 .m.. Area behind buildin to be sealed with dial sides on Saturda or Sunda rnornin
weather permitting. _
EXHIBIT VII
AGREEMENT CREATING LIEN ON REAL ESTATE
Th undersigned, a, "J 4-t. 4. /V i 0 � _ , owner(s) of
(04 ;r,. 0..v (. , Lemont, Illinois, having applied for
Building & Site Improvement Grant Program from the Village of Lemont through the
General Fund Financing does hereby grant a lien to the Village of Lemont, a Municipal
Co oration, in the amount of Ti;vi." 0-r.)0 )x,c/p01p2_ ,Fe/tc( Dollars
($ (p (j0, at on the property commonly known as ( kJ 4 7� - ro 4- o 56 et-4e 9.4 L-0/x
Lemont, Illinois 60439, and legally described as follows:
Permanent Index Number: 2), - gq v 3C) ! -0?4 - O O Q C)
The undersigned acknowledges that the aforesaid lien shall exist from the date of
this instrument, and shall become due if any facade alterations occur less than three years
after grant work completion. If this condition occurs, then the lien shall be payable to the
Village of Lemont. If this condition does not occur, then the lien shall be removed.
The undersigned grants to the Village of Lemont the right to assign, transfer or set
over to any other municipal corporation or any part thereof all of the right, title and interest
in and to said lien without reservations.
DATED this q rd day of 5t-a7- , 1999.
Form Rev. 7/99
STATE OF ILLINOIS }
} SS:
COUNTY OF COOK }
I, the undersigned, a Not Public in and for said County, in the State aforesaid,
DO HEREBY CERTIFY that di-) `1 4 . 4 co ec -- is
known to me to be the same person(s) whose name(s) is/are subscribed to the foregoing
instrument, appeared before me this day in person, and acknowledged that he /she /they
signed, sealed, and delivered the said instrument as a free and voluntary act for the uses and
purposes therein set forth.
I roman SEAL'
lbws P. Nagel
Nem MSc, State of Illinois
XD Commission Expires VP r'""
This instrument was prepared by:
VILLAGE OF LEMONT
418 Main Street
Lemont, Illinois 60439
(630) 257 -6440