Loading...
R-81-99 Approving Village Participation in Non-tif District Sign Grant ProgramVILLAGE OF LEMONT RESOLUTION NO. N-et -q DATE /o -,5 -q5 GRANT A RESOLUTION APPROVING VILLAGE PARTICIPATION IN NON - TIF DISTRICT SIGN GRANT PROGRAM WHEREAS, the Village of Lemont has adopted Ordinance 0- 72 -99, the Non -Tif Building & Site Grant, Sign Grant and Low Interest Loan Programs, to provide incentives for building reinvestment within the Village of Lemont's Non -Tif District; and WHEREAS, in accordance with the Non -Tif District Sign Grant, the Village Board of Trustees shall consider participation in building reinvestment; and WHEREAS, Francisco Manuel, as the property owner for the property known as 14315 McCarthy Road has completed the Non -Tif Sign Grant application for Village participation of said property; and WHEREAS, Village Staff has reviewed the 14315 McCarthy Road application for compliance with the Non -Tif Sign Grant guidelines and has recommended approval of the request. NOW, THEREFORE, BE IT RESOLVED, that the Village President is authorized to execute the Sign Grant Agreement attached for Seven Hundred Fifty Dollars ($750.00) in accordance with the terms of the Non -Tif District Sign Grant guidelines. PASSED AND APPROVED BY THE PRESIDENT AND BOARD OF TRUSTEES OF THE VILLAGE OF LEMONT, COUNTIES OF COOK, DuPAGE AND WILL, ILLINOIS, on this 0154"day of a) , 1999. John Benik Debby Blatzer Keith Latz Connie Markiewicz Rick Rimbo Mary Studebaker AYES NAYS PASSED ABSENT V V V Approved by me this`'25 day of Attest: erAAW CHARLENE SMOLLEN, Village Clerk IPOA \ kket Try , ' D 7. KWASNESKI, Village President 1999. HARLENE SMOLL N, Village Clerk APP OVED AS TO FORM: Village Attorn VILLAGE OF LEMONT PRIVATE SIGNAGE IMPROVEMENT PROGRAM AGREEMENT NON -TIF DISTRICT THIS AGREEMENT, entered into this day of , , between the Village of Lemont, Illinois (hereinafter referred to as the "Village ") and the following designated OWNER/LESSEE, to wit: FRAN,Cdt&CO Nu Owner's/Lessee's Name: Name of Business: MA NI u E `- U y 1 S 1, a r K y ( Address: � +-� 3 (`J M ► G�-A, r Z "`' Co � a City: L E M 0 IJ T State: l t. l Zip Code: WITNESSETH Whereas, the VILLAGE has established a Private Signage Improvement Program for application within certain designated commercial areas outside of the VILLAGE Tax Increment Financing District: and Whereas, said Private Signage Improvement Program is administered by the VILLAGE and is funded from General Revenues for purposes of control and prevention of blight, dilapidation and deterioration of designated areas within the Village, and Whereas, pursuant to said Program the VILLAGE has agreed to participate, subject to its sole discretion, in sharing the cost of Signage Improvements to commercial establishments within the District up to a maximum of one -half (1/2) of the approved contract cost of such improvement but in no event shall the total Village participation exceed Seven Hundred Fifty Dollars ($750.00) per sign for sign design and sign procurement; and Whereas, the OWNER's/LESSEE's property is located within the Commercial area of the Village, and the OWNER/LESSEE desires to participate in the Private Signage Improvement Program pursuant to the terms and provisions of this agreement. NOW, THEREFORE, in consideration of the mutual covenants and agreement obtained herein, the VILLAGE and OWNER/LESSEE do hereby agree as follows: SECTION 1: COST SHARING - The VILLAGE shall share in the signage design and procurement costs for the OWNER's/LESSEE's property up to fifty percent (50 %), up to a maximum amount not exceeding Seven Hundred Fifty Dollars ($750.00) per sign. The actual amount per this agreement shall not exceed $ 7--SG' • The signage design and procurement costs which are eligible for VILLAGE participation include all labor, materials, equipment and other contract items necessary for the proper execution and completion of the work as designated from the design drawings approved by the VILLAGE. Said design drawings and specifications are attached hereto as Exhibit IV. SECTION 2: DESIGN APPROVAL - No private signage work shall be undertaken until the following is completed: • The application has been completed and approved by the Village; • The design therefore has been submitted to and approved by the Building Department/Community Development Department for code compliance; • The Village has determined the proposal meets the intent of the Downtown Sign Ordinance; • The sign is being installed by an accredited, licensed sign professional; No Application shall be processed or approved in cases when non - conforming signs exist on the building; unless the conflict has been resolved prior to the approval. No private signage work shall be undertaken until the design therefore has been submitted to and approved by the Building Department. Following approval, the OWNER/LESSEE shall contract for the work and shall commence and complete all such work within one hundred eighty (180) days from the date of such approval. Following approval, the OWNER/LESSEE shall contract for the work and shall commence and complete all such work within one hundred eighty (180) days from the date of such approval. SECTION 3: REVIEW OF PROJECT - The Economic Development Coordinator shall periodically review the progress of the contractor's work on the signage pursuant to this Agreement. Such inspections shall not replace any required permit inspection by Village Inspectors. All work which is not in conformance with the approved drawings and specifications shall be immediately remedied by the OWNER/LESSEE and deficient or improper work shall be replaced and made to comply with the approved drawings, specifications, and terms of this Agreement. SECTION 4: DOCUMENTATION REQUIREMENTS - Upon completion of the signage improvement and upon its final inspection and approval by the Building Department, the OWNER/LESSEE shall submit to the VILLAGE a properly executed and notarized contractor statement showing the full cost of the work as well as each separate component amount due to the contractor and each and every subcontractor involved in furnishing labor, materials, or equipment in the work. In addition, the OWNER/LESSEE shall submit to the VILLAGE proof of payment of the contract cost pursuant to the contractor's statements. The VILLAGE shall, within thirty (30) days of receipt of the contractor's statement and proof of payment issue a check to the OWNER/LESSEE in payment of one -half of the approved cost or Seven Hundred Fifty Dollars ($750) whichever is less. In no case shall the amount paid to the OWNER/LESSEE exceed the amount specified in this Agreement or in the contractor's statements. At time of reimbursement and a throughout the term of this agreement, all signage under the control of the OWNER/LESSEE shall be in conformance with Village sign code provisions. SECTION 5: FAILURE TO COMPLETE WORK - If the OWNERJLESSEE or his contractor fail to complete the signage improvement work provided for herein in conformity with the plans, specifications and terms of this Agreement, the Agreement shall terminate and the financial obligation on the part of the VILLAGE shall cease and become null and void. SECTION 6: MAINTENANCE OF IMPROVEMENTS - Upon completion of the signage improvement work pursuant to this Agreement and for a period of three (3) years thereafter, the OWNER/LESSEE shall be responsible for properly maintaining such signage improvement in its finished form and without change or alteration thereto, as provided in this Agreement, and for the said period of three (3) years following completion of the construction thereof, the OWNER/LESSEE shall not enter into any Agreement or contract or take any other steps to alter, change or remove such signage, or the approved design thereof, nor shall OWNER/LESSEE undertake any other changes, by contract or otherwise, to the improvement provided for in this Agreement unless such changes are first submitted to the Economic Development Coordinator, and any additional review body or commission designated for approval; which approval shall not be unreasonably with held if the proposed changes do not substantially alter the original design concept of the signage as specified in the drawings and plans approved pursuant to this Agreement. SECTION 7: UNRELATED IMPROVEMENT - Nothing herein is intended to limit, restrict or prohibit the OWNER/LESSEE from undertaking any other work in or about the subject premises which is unrelated to the signage improvement provided for in this Agreement. SECTION 8: AGREEMENT APPLICABLE TO FUTURE OWNERS - This Agreement shall be binding upon the VILLAGE OF LEMONT and upon the OWNER/LESSEE, to said property for a period of three (3) years from and after the date of completion and approval of the signage improvement provided for herein. It shall be the responsibility of the OWNER/LESSEE to inform subsequent OWNER(s)/LESSEE(s) of Section 6 of this Agreement. SECTION 9. MAXIMUM GRANT AWARDS - Nothing in this Agreement shall prohibit a business property owner from applying for more than one Grant. However, a Ten Thousand Seven Hundred Fifty Dollar ($10,750.00) limitation shall apply to all Sign Grants, Building and Site Improvement Grants, or Interest Rate Program Awards made to a single building and/or lot within any three (3) year period. For the purpose of calculating the three (3) year period, the date of the last Village payment shall be considered the start of the three (3) year period. SECTION 10: CONSTRUCTION INDEMNIFICATION - The owners of the subject property agree to defend and hold harmless the Village from any and all claims which may arise out of said owners' construction activities under this Agreement. SECTION 11: GENERAL LNDEMNIFICATION - In the event that, as a result of this Agreement, or actions taken as required hereunder, the Village is made a party defendant in any litigation arising by reason of this Agreement, or the construction and development activities contemplated hereunder, the owners agree to defend and hold harmless the Village, the mayor, trustees, officers and agents thereof, individually and collectively, from any suits and from any claims, demands, setoff or other action including but not limited to judgments arising therefrom. The obligation of the owners hereunder shall include and extend to payment of reasonable attorneys' fees for the representation of the Village and its said officers and agents in such litigation and includes expenses, court costs and fees; it being understood that the owners where there shall be no applicable standards provided therein, shall have the right to employ all such attorneys to represent the Village and its officers and agents in such litigation, subject to the approval of the corporate authorities of the Village, which approval shall not be unreasonably withheld. The owners shall have the right to appeal to courts of appellate jurisdiction any judgment taken against the Village or its officers or agents in this respect, and the Village shall join in any such appeal taken by the owners. SECTION 12: PERFORMANCE OF AGREEMENT - It is agreed that the parties hereto may in law or in equity, by suit, action, mandamus, or any other proceeding, including specific performance, enforce or compel the performance of this Agreement, which shall include the right of the parties to recover a judgment for monetary damages against each other, provided, however, that the owners shall not have a right to recover a judgment for monetary damages against any elected or appointed official of the Village for any breach of any of the terms of this Agreement. The Village reserves the right to maintain an action to recover damages or any sums which owners have agreed to pay pursuant to this Agreement and which have become due and remained unpaid. SECTION 13: EXHIBITS - It is agreed that exhibits I through V shall be considered part of this agreement. SECTION 14: DISPLAY OF VILLAGE FUNDING PROMOTIONAL MATERIAL - All program participants shall be required to prominently display a poster identifying the property as receiving Village funding. The sign will be provided by the Village and shall be displayed from the date the application is approved, to no less than thirty (30) days after final approval and reimbursement is made. IN WITNESS THEREOF, the parties hereto have executed this Agreement on the date first appearing above. 3 OWNERS/LESSEE P ra Participant DATE: $ f>-- N Pro Owner DATE: Si (?. 5 l a� GE OF LE1 IONT Rev. 7/99 9 DATE: age President to - 015 -q'1 DATE: /d -X5.9y EXHIBITS EXHIBIT I PROOF OF OWNERSHIP E BIT EXHIBIT III COPY OF APPLICATION SIGNAGL PLANS EXHIBIT V CONTRACTOR'S AGREEMENT ALTA OWNERS POLICY 4 -6 -90 INTERCOUNTY EXHIBIT I POLICY OF TITLE INSURANCE ISSUED BY POLICY NUMBER 17100000051811 IAT1L'FLEIN*CE COMPANY SUBJECT TO THE EXCLUSIONS FROM COVERAGE, THE EXCEPTIONS FROM COVERAGE CONTAINED IN SCHEDULE B AND THE CON- DITIONS AND STIPULATIONS, INTERCOUNTY NATIONAL TITLE INSURANCE COMPANY, herein called the Company, insures, as of Date of Policy shown in Schedule A, against loss or damage, not exceeding the Amount of Insurance stated in Schedule A, sustained or incurred by the insured by reason of: 1. Title to the estate or interest described in Schedule A being vested other than as stated therein; 2. Any defect in or lien or encumbrance on the title; 3. Unmarketability of the title; 4. Lack of a right of access to and from the land; The Company will also pay the costs, attorneys' fees and expenses incurred in defense of the title, as insured, but only to the extent provided in the Conditions and Stipulations. IN WITNESS WHEREOF, Intercounty National Title Insurance Company has caused this policy to be signed and sealed by its duly authorized officers as of the Date of Policy shown in Schedule A. EXCLUSIONS FROM COVERAGE The following matters are expressly excluded from the coverage of this policy and the Company will not pay loss or damage, costs, attorneys' fees or expens- es which arise by reason of: 1. (a) Any law, ordinance or government regulation (including but not limited to building and zoning laws, ordinances, or regulations) restricting, regulating, prohibiting or relating to (i) the occupancy, use, or enjoyment of the land; (ii) the character dimensions or location of any improvement now or hereafter erected on the land; (iii) a separation in ownership or a change in the dimensions or area of the land or any parcel of which the land is or was part; or (iv) environmental protections, or the effect of any violation of these laws, ordinances or governmental regulations, except to the extent that a notice of the enforcement thereof or a notice of a defect, lien or encumbrance resulting from a violation or alleged violation affecting the land has been recorded in the public records at Date of Policy. (b) Any governmental police power not excluded by (a) above, except to the extent that a notice of the exercise thereof or a notice of a defect, lien or encum- brance resulting from violation or alleged violation affecting the land has been recorded in the public records at Date of Policy. 2. Rights of eminent domain unless notice of the exercise thereof has been recorded in the public records at Date of Policy, but not excluding from coverage any taking which has occurred prior to Date of Policy which would be binding on the rights of a purchaser for value without knowledge. 3. Defects, liens encumbrances, adverse claims or other matters: (a) created, suffered, assumed or agreed to by the insured claimant; (b) not known to the Company, not recorded in the public records at Date of Policy, but known to the insured claimant and not disclosed in writing to the Company by the insured claimant prior to the date the insured claimant became an insured under this policy; (c) resulting in no loss or damage to the insured claimant; (d) attaching or created subsequent to Date of Policy; or (e) resulting in loss or damage which would not have been sustained if the insured claimant had paid value for the estate or interest insured by this policy. 4. Any claim, which arises out of the transaction vesting in the Insured the estate or interest insured by this policy, by reason of the operation of federal bank - ruptcy, state insolvency, or similar creditors' rights laws that is based on: (a) the transaction creating the estate or interest insured by this policy being deemed a fraudulent conveyance or fraudulent transfer; or (b) the transaction creating the estate or interest insured by this policy being deemed a preferential transfer except where the preferential transfer results from the failure: (continued on inside cover) INTERCOUNTY NATIONAL TITLE INSURANCE COMPANY Countersigned 6t. President iJ • et944ULSS& Secretary Authorized Signatory SEAL ISSUED ON BEHALF OF INTERCOUNTY NATIONAL TITLE INSURANCE COMPANY BY: Number S1552721 1. Name of Insured: A.L.T.A. OWNER'S FORM SCHEDULE A Amount of Policy $45,000.00 Date of Policy: December 29, 1998 FRANCISCO MANUEL AND CARIDAD MANUEL, HIS WIFE. 2. Title to the estate or interest in the land described or referred to in this Schedule covered by this Policy is: FEE SIMPLE, IN JOINT TENANCY. 3. Title to the estate or interest covered by this Policy at the date hereof is vested in the insured. 4. The land referred to in this Policy is described as follows: THE WEST 1/2 OF THE EAST 214 FEET OF THE WEST 687.90 FEET OF THE SOUTH 214 FEET OF THE SOUTHWEST 1/4 OF THE NORTHWEST 1/4 OF SECTION 27, TOWNSHIP 37 NORTH, RANGE 11, EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS. Countersigned: 0,1:t1 AUTHORIZED SIGNATORY INTERCOUNTY TITLE COMPANY 120 WEST MADISON STREET CHICAGO, IL 60602 (312) 977 -2600 This Policy valid only if Schedule B is attached. A.L.T.A. OWNER'S FORM SCHEDULE B Number S1552721 This Policy does not insure against loss or damage by reason of the following: 1. GENERAL REAL ESTATE TAXES FOR THE YEAR 1998. TAX NUMBER 22- 27100 -026, VOLUME 62. (AFFECTS SUBJECT LAND AND OTHER LAND) NOTE: THE 1998 TAXES ARE NOT YET DUE AND PAYABLE. 2. DRAINAGE DITCHES, FEEDERS AND LATERALS, AND OTHER DRAINAGE EASEMENTS, IF ANY. THE STANDARD EXCEPTIONS REFERRED TO ON THE INSIDE FRONT COVER. Countersigned: AUTHORIZED SIGNATORY ENDORSEMENT Number S1552721 * * * * ** *OWNERS COMPREHENSIVE ENDORSEMENT NO. 1 * * * * * ** THE COMPANY HEREBY INSURES THE INSURED AGAINST LOSS OR DAMAGE WHICH THE INSURED SHALL SUSTAIN BY REASON OF: A. THE REMOVAL FROM THE LAND OF AN EXISTING RESIDENCE RESULTING FROM: (1) ANY VIOLATION OF COVENANTS, CONDITIONS OR RESTRICTIONS SHOWN IN SCHEDULE B; (2) ANY VIOLATION OF EXISTING ZONING ORDINANCES. B. ANY INTERFERENCE WITH THE USE OF THE LAND FOR SINGLE FAMILY RESIDENCE PURPOSES RESULTING FROM: (1) ANY VIOLATION OF COVENANTS, CONDITIONS OR RESTRICTIONS SHOWN IN SCHEDULE B; (2) ANY VIOLATION OF EXISTING ZONING ORDINANCES. THIS ENDORSEMENT SHALL BE EFFECTIVE ONLY IF AT THE DATE OF THIS POLICY THE LAND DESCRIBED IN SCHEDULE A: A. IS IMPROVED WITH A SINGLE FAMILY RESIDENCE OR A CONDOMINIUM UNIT, OR AN APARTMENT BUILDING CONTAINING NO MORE THAN FOUR UNITS, AS TO THE COVERAGE PROVIDED IN PARAGRAPH A ABOVE. B. IS IMPROVED WITH A SINGLE FAMILY RESIDENCE OR A CONDOMINIUM UNIT, AS TO THE COVERAGE PROVIDED IN PARAGRAPH B ABOVE. THIS ENDORSEMENT IS SUBJECT TO ANY SPECIFIC VIOLATIONS NOTED IN SCHEDULE B OF THE POLICY. FOR PURPOSES OF THIS ENDORSEMENT, PLANTINGS, PERIMETER FENCES, PERIMETER WALLS OR ACCESSORY STRUCTURES ARE NOT SUBJECT TO COVERAGE. This Endorsement is continued on the next page. ENDORSEMENT Number S1552721 OWNERS COMPREHENSIVE ENDORSEMENT NO. 1 - Continued This Endorsement is made part of the Policy and is subject to all of the terms and provisions thereof and of any prior endorsements thereto. Except to the extent expressly stated; it does not modify any of the terms and provisions of the Policy and prior endorsements, if any. Countersigned: Or Lett, 1 'iz(\mAn AUTHORIZED SIGNATORY This Endorsement valid only if countersigned. ENDORSEMENT Number S1552721 * * * * * * * * * * * * * * * ** *INFLATION RIDER * * * * * * * * * * * * * * * * ** * * * * * * * * ** *TITLE INSURANCE FOR HOMEOWNERS * * * * * * * * ** THE UNDERSIGNED INSURING COMPANY HEREBY CERTIFIED THAT NOTWITHSTANDING ANYTHING THEREIN CONTAINED TO THE CONTRARY, THE ATTACHED POLICY SHALL BE SUPPLEMENTED AND MODIFIED AS FOLLOWS: THE AMOUNT OF INSURANCE PROVIDED BY THE TITLE INSURANCE POLICY TO WHICH THIS RIDER IS ATTACHED, AS STATED IN SCHEDULE A THEREOF, IS SUBJECT TO CUMULATIVE ANNUAL UPWARD ADJUSTMENTS IN THE MANNER AND TO THE EXTENT HEREINAFTER SPECIFIED. "ADJUSTMENT DATE" IS DEFINED, FOR PURPOSES OF THIS RIDER, TO BE 12:01 A.M. ON THE FIRST JANUARY 1 WHICH OCCURS MORE THAN NINE MONTHS AFTER THE DATE OF POLICY OF THE TITLE INSURANCE POLICY TO WHICH THIS RIDER IS ATTACHED, AS SHOWN IN SCHEDULE A THEREOF, AND 12:01 A.M. ON EACH JANUARY 1 THEREAFTER; PROVIDED, HOWEVER, THERE SHALL BE NO MORE THAN TEN ADJUSTMENT DATES ON WHICH THE AMOUNT OF INSURANCE PROVIDED BY SUCH TITLE INSURANCE POLICY SHALL BE ELIGIBLE FOR UPWARD ADJUSTMENT. AN UPWARD ADJUSTMENT WILL BE MADE ON EACH ADJUSTMENT DATED (AS DEFINED ABOVE) BY INCREASING THE AMOUNT OF INSURANCE PROVIDED BY SUCH POLICY (AS SAID AMOUNT MAY HAVE BEEN INCREASED THERETOFORE) BY THE SAME PERCENTAGE, IF ANY, BY WHICH THE UNITED STATES DEPARTMENT OF COMMERCE CONSTRUCTION COST INDEX (BASE PERIOD 1967) FOR THE MONTH OF OCTOBER ONE YEAR EARLIER; PROVIDED, HOWEVER, THAT THE AMOUNT OF SUCH INSURANCE SHALL, IN NO EVENT, BE INCREASED BY MORE THAN 8% ON ANY ONE ADJUSTMENT DATE. THERE SHALL BE NO ANNUAL ADJUSTMENT IN AMOUNT OF INSURANCE FOR YEARS IN WHICH THERE IS NO INCREASE IN THE UNITED STATES DEPARTMENT OF COMMERCE CONSTRUCTION COST INDEX. IN THE SETTLEMENT OF ANY CLAIM MADE AGAINST THE INSURER ON THE TITLE INSURANCE POLICY TO WHICH THIS RIDER IS ATTACHED, THE AMOUNT OF INSURANCE PROVIDED BY SUCH POLICY SHALL BE DEEMED TO BE THE AMOUNT WHICH IS IN FORCE AS OF THE DATE ON WHICH THE CLAIMANT FIRST LEARNS OF THE ASSERTION OR POSSIBLE This Endorsement is continued on the next page. Number S1552721 ENDORSEMENT Page 2 ASSERTION OF SUCH CLAIM OR AS OF THE DATE OF RECEIPT BY THE COMPANY OF THE FIRST NOTICE OF SUCH CLAIM, WHICHEVER SHALL FIRST OCCUR. This Endorsement is made part of the Policy and is subject to all of the terms and provisions thereof and of any prior endorsements thereto. Except to the extent expressly stated; it does not modify any of the terms and provisions of the Policy and prior endorsements, if any. Countersigned: AUTHORIZED SIGNATORY This Endorsement valid only if countersigned. Applicant Name: EXHIBIT III File Number: VILLAGE OF LEMONT PRIVATE SIGNAGE IMPROVEMENT GRANT NON -TIF DISTRICT APPLICATION Project Address(es): 114 3 P C IV, Cc- ` Lt MO Al ) L- 00439 Building Owner: f C L A. t$ CA S C E CAN' t a M A V►cte {ear Purchased: Store/Company Name: A a mu- L Lo It I.S f t G OM- n Co- 0 Name of Tenant: Lease Expiration Date: Applicant Name: 5.62. C- S Co t Aki el Applicant Business Address: Ili 3I 5 M CGA. Y'4&y Applicant Business Phone: ID 30-0544 3Home Phone: Applicant(s): Building Owner: Tenant: Number of Signs (max. three): Total Anticipated Budget: $ 1 5 0 0.0 c, Total Anticipated Grant Request: $ 7 0.0 0 Description of Proposed Sipage:* 0 0 u tO0A- itIL €44 1/L0 vrtsb sel GTO' 404 7 •S' )4g ( * Signage placement on building Applicant Name: File Number: PICTURE OF STORE FRONT AND PLACEMENT OF SIGNAGE ON STOREFRONT: 1 1 a 8 1/2" X 10" PHOTO Applicant Name: File Number: I, {�'1(6ti YY eAA KA'VI,tl-A' , hereby make application to the Village of Lemont for a Private Signage Improvement Grant in the anticipated amount of $ 7 5 0 I understand that my application must be approved by the Village and that it must conform to established design guidelines, as well as, specific design recommendations of the Village of Lemont. I have read a copy of the Signage Improvement Program Agreement. If approved, I understand that all work performed is subject to development, building, permit, and agreement provisions. App ant ggnature Date 9 Buil ' Q er Please return the completed application to: Economic Development Coordinator Village of Lemont 418 Main Street Lemont, IL 60439 f)vc) Date If you need assistance with the application and/or have general inquiries, please contact the Economic Development Coordinator at (630) 257 -6440. Applicant Name: r12 A it \c (t e L- File Number: BUDGET (anticipated) Total Anticipated Grant Request: $ Sign Designer for the Project: Name: W\ k t - OVA 1r Address: W9 -y1" on T Phone: 7SV•0d Contractor for the Project: Name: Address: Phone: VYl i Imo. \ {0va r VJ A- s T vVl o tA. I Application will be reviewed by the Economic Development Coordinator, Building Department and Community Development Director. ACTIVITY ESTIMATED COST IDotA ' f c NnUw\eh 51 v1l•S •ii 154 0.G CJ Total Anticipated Grant Request: $ Sign Designer for the Project: Name: W\ k t - OVA 1r Address: W9 -y1" on T Phone: 7SV•0d Contractor for the Project: Name: Address: Phone: VYl i Imo. \ {0va r VJ A- s T vVl o tA. I Application will be reviewed by the Economic Development Coordinator, Building Department and Community Development Director. F R 0 PROPOSAL EXHIBIT V ?age No. of Pages We hereby propose to furnish labor and materials in co lete accordance with the above specifications, for the sum of dollars ( 1 SO 0 ) with payment to be made as follows: All material is guaranteed to be as specified. All work to be completed in a workmanlike manner according to standard practices. Any alteration or deviation from above specifications involving extra costs, will be executed only upon written orders, and will become an extra charge over and above the estimate. All agreements are contingent upon strikes, accident or delays beyond our control. This proposal is subject to acceptance within days and is void thereafter at the option of the undersigned. 06, f■DIN)1%) /--st 00 C .0. , Oh) 1V.ILI1)6 Authorized Signature ACCEPTANCE OF PROPOSAL The above prices, specifications and conditions are hereby accepted. You are authorized to do the •ork as specified. Payment will be made as outlined above. ACCEPTED: �[ 6 Signature: Date: 2 Signature: © E -Z Contractors Forms FORM NO. EZ 110 -1 AZHH 00600 PROPOSAL SUBMITTED TO: PHONE DATE N g 2 /fei NAME I,�r1vt/vj't " ' \ay-i c'�� ^y�. _ _�JnB C�/�u -, G STREET STREET r31 s /A I/All &o_ STATE CITY CITY STATE We hereby propose to furnish labor and materials in co lete accordance with the above specifications, for the sum of dollars ( 1 SO 0 ) with payment to be made as follows: All material is guaranteed to be as specified. All work to be completed in a workmanlike manner according to standard practices. Any alteration or deviation from above specifications involving extra costs, will be executed only upon written orders, and will become an extra charge over and above the estimate. All agreements are contingent upon strikes, accident or delays beyond our control. This proposal is subject to acceptance within days and is void thereafter at the option of the undersigned. 06, f■DIN)1%) /--st 00 C .0. , Oh) 1V.ILI1)6 Authorized Signature ACCEPTANCE OF PROPOSAL The above prices, specifications and conditions are hereby accepted. You are authorized to do the •ork as specified. Payment will be made as outlined above. ACCEPTED: �[ 6 Signature: Date: 2 Signature: © E -Z Contractors Forms FORM NO. EZ 110 -1 AZHH 00600