Loading...
R-90-99 Approving Village Participation in TIF Building and Site Grant ProgramVILLAGE OF LEMONT RESOLUTION NO. v 9 DATE it-7:2.-11 GRANT A RESOLUTION APPROVING VILLAGE PARTICIPATION IN TIF BUILDING AND SITE GRANT PROGRAM WHEREAS, the Village of Lemont has adopted Ordinance 0- 71 -99, the Downtown Building & Site Improvement Grant, Sign Grant and Low Interest Loan Programs, to provide incentives for building reinvestment within the Village of Lemont's Tax Increment Financing District; and WHEREAS, in accordance with the Downtown Building & Site Improvement Grant, the Village Board of Trustees shall consider participation in building reinvestment; and WHEREAS, Jung Y. Lim, as the property owner for the property known as 210 Main Street has completed the Downtown Building & Site Improvement Grant application for Village participation of said property; and WHEREAS, Village Staff has reviewed the 210 Main Street application for compliance with the Downtown Building & Site Improvement Grant guidelines and has recommended approval of the request. NOW, THEREFORE, BE IT RESOLVED, that the Village President is authorized to execute the Building and Site Grant Agreement attached for One Thousand Sixty -Two Dollars ($1,062.00) in accordance with the terms of the Downtown Building & Site Improvement guidelines. PASSED AND APPROVED BY THE PRESIDENT AND BOARD OF TRUSTEES OF THE VILLAGE OF 1EMONT, COUNTIES OF COOK, DuPAGE AND WILL, 7�' ILLINOIS, on this Z ay of 110➢i9Ar►9/' , 1999. John Benik Debby Blatzer Keith Latz Connie Markiewicz Rick Rimbo Mary Studebaker AYES NAYS PASSED ABSENT v Approved by me this Z ay of t IMOAM19 , 1999. Village Clerk J i// RICH RD A. ASNES I Village Presi Vi . ge Clerk APPROVED AS TO FORM: c Village Attorney( t lfi L f/y?rtd. v J VILLAGE OF LEMONT BUILDING AND SITE IMPROVEMENT GRANT PROGRAM AGREEMENT NON -TIF DISTRICT THIS AGREEMENT, entered into this day of , , between the Village of Lemont, Illinois (hereinafter referred to as the "Village ") and the following designated OWNER/LESSEE, to wit: — Owner's/Lessee's Name: J A ,.CJ y W1 Address: .0? JO new 4 in) .5-free City: Len) Oh -& State: 1 L-- Zip Code: Name of Business: Project Address(es) Leib bn + fiou.se Res rah- 021 /1A it) S-f ree 4 WITNESSETH Whereas, the VILLAGE has established a Building & Site Improvement Grant Program for application within designated commercial areas outside of the VILLAGE Tax Increment Financing District; and Whereas, said Building & Site Improvement Grant Program is administered by the VILLAGE and is funded from General Revenues for purposes of control and prevention of blight, dilapidation and deterioration of designated areas within the Village, and Whereas, pursuant to said Program the VILLAGE has agreed to participate, subject to its sole discretion, in sharing the cost of Building & Site Improvements to commercial establishments within the District up to a maximum of one -half (1/2) of the approved contract cost of such improvement but in no event shall the total Village participation exceed Ten Thousand Seven Hundred Fifty Dollars($10,750.00) for construction and architectural cost with $750.00 of that amount reserved for sign improvements only. Architectural fees shall be limited to a One Thousand Dollars ($1,000.00) reimbursement; and Whereas, the OWNER's/LESSEE's property is located within the commercial area of the Village, and the OWNER/LESSEE desires to participate in the Building and Site Improvement Grant Program pursuant to the terms and provisions of this agreement. NOW, THEREFORE, in consideration of the mutual covenants and agreement obtained herein, the VILLAGE and OWNER/LESSEE do hereby agree as follows: SECTION 1: COST SHARING - The VILLAGE shall share in the building and site improvement cost and architect fee cost for the OWNER's/LESSEE's property up to fifty percent (50 %), up to a maximum amount not exceeding Ten Thousand Seven Hundred Fifty Dollars ($10,750.00) for construction and architectural cost with $750.00 reserved for sign improvements. Architectural reimbursement shall be One Thousand Dollars ($1,000.00) . The actual amount per this agreement shall not exceed $ O62, 4or for architect fees. The building cost and $ :J g and site improvement 2 /historic preservation costs which are eligible for VILLAGE participation include all labor, materials, equipment and other contract items necessary for the proper execution and completion of the work as designated from the design drawings approved by the VILLAGE. Said design drawings and specifications are attached hereto as Exhibit IV. SECTION 2: DESIGN APPROVAL - No building and site improvement or historic preservation work shall be undertaken until the design therefore has been submitted to and approved by the Village. Following approval, the OWNER/LESSEE shall contract for the work and shall commence and complete all such work within one hundred eighty (180) days from the date of such approval. SECTION 3: REVIEW OF PROJECT - The Economic Development Coordinator shall periodically review the progress of the contractor's work on the building and site improvement and historic preservation pursuant to this Agreement. Such inspections shall not replace any required permit inspection by Village Inspectors. All work which is not in conformance with the approved drawings and specifications shall be immediately remedied by the OWNER/LESSEE and deficient or improper work shall be replaced and made to comply with the approved drawings, specifications, and terms of this Agreement. SECTION 4: DOCUMENTATION REQUIREMENTS, - Upon completion of the building and site improvement/historic preservation and upon its final inspection and approval by the Building Department, the OWNER/LESSEE shall submit to the VILLAGE a properly executed and notarized contractor statement and architect fee statement showing the full cost of the work as well as each separate component amount due to the contractor and each and every subcontractor involved in furnishing labor, materials, or equipment in the work. In addition, the OWNER/LESSEE shall submit to the VILLAGE proof of payment of the contract cost pursuant to the contractor's and architect's statements. The VILLAGE shall, within thirty (30) days of receipt of the contractor's statement and proof 3 of payment issue a check to the OWNER/LESSEE in payment of: one -half of the approved cost or Ten Thousand Seven Hundred Fifty Dollars ($10,750.00) whichever is less. In no case shall the amount paid to the OWNER/LESSEE exceed the amount specified in this Agreement or in the contractor's or architect's statements. At the time of reimbursement and throughout the term of this agreement, the land use and signage under the control of the OWNER/LESSEE shall be in conformance with zoning and sign code provisions. SECTION 5: FAILURE TO COMPLETE WORK - If the OWNER/LESSEE or his contractor fail to complete the building and site improvement/historic preservation work provided for herein in conformity with the plans, specifications and all terms of this Agreement, the Agreement shall terminate and the financial obligation on the part of the VILLAGE shall cease and become null and void. SECTION 6: ELIGIBLE IMPROVEMENT WORK - Installation, repair and replacement of exit doors and hardware; repair, replacement or addition of exterior shutters and awnings/canopies; repair, replacements or purchase of signs when done as part of an overall building and site improvement grant; repair and replacement or installation of exterior stairs, porches, railings and exit facilities; repair and rebuilding of exterior walls, including cleaning, sealing, tuck pointing and painting; repair of window frames, sills, glazing, replacement of glass and installation of new windows; installation of landscaping such as stone or brick planters; paving for existing parking lots, lighting & striping (does not apply to new parking lots or expansion of existing parking lots); replacing or upgrading of stormwater, curbing, replacement of retaining walls, electrical wiring upgrades, interior sprinkler systems, fire alarm systems, elevators, interior floor, ceiling improvements, plumbing and improvements to meet ADA requirements. SECTION 7: FILING OF LIEN/MAINTENANCE OF IMPROVEMENT - Upon completion of the building and site improvement work pursuant to this Agreement and for a 4 period of three (3) years thereafter, the OWNER/LESSEE shall be responsible for properly maintaining such building and site improvement/historic preservation in its finished form and without change or alteration thereto, as provided in this Agreement, and for the said period of three (3) years following completion of the construction thereof, the OWNER/LESSEE shall not enter into any Agreement or contract or take any other steps to alter, change or remove such improvement, or the approved design thereof, nor shall OWNER/LESSEE undertake any other changes, by contract or otherwise, to the improvement provided for in this Agreement unless such changes are first submitted to the Economic Development Coordinator, and any additional review body or commission for approval; which approval shall not be unreasonably withheld if the proposed changes do not substantially alter the original design concept of the building and site improvements as specified in the drawings and plans approved pursuant to this Agreement. In addition to this section, a lien on the OWNER/LESSEE property shall be filed prior to the final payout of the program reimbursement. SECTION 8: UNRELATED IMPROVEMENTS - Nothing herein is intended to limit, restrict or prohibit the OWNER/LESSEE from undertaking any other work in or about the subject premises which is unrelated to the building and site improvement provided for in this Agreement. SECTION 9: AGREEMENT APPLICABLE TO FUTURE OWNERS - This Agreement shall be binding upon the VILLAGE OF LEMONT and upon the OWNER/LESSEE and its successors, to said property for a period of three (3) years from and after the date of completion and approval of the facade improvement provided for herein. It shall be the responsibility of the OWNER/LESSEE to inform subsequent OWNER(s)/LESSEE(s) of Section 7 of this Agreement. 5 SECTION 10: MAXIMUM GRANT AWARDS - Nothing in this Agreement shall prohibit a business or property owner from applying for more than one Grant. However, a Ten Thousand Seven Hundred Fifty Dollars ($10,750.00) total limitation shall apply to all Sign Grants, Building and Site Grants or Interest Rate Program Awards made to a single building and/or lot within any three (3) year period. For the purpose of calculating the three (3) year period, the date of the last Village payment shall be considered the start of the three (3) year period. No grant may be utilized for the same or similar building contract work, within a ten (10) year period of the last Village payment. SECTION 11: VILLAGE INDEMNIFICATION REGARDING CONSTRUCTION The owners of the subject property agree to defend and hold harmless the Village from any and all claims which may arise out of said owners' construction activities under this Agreement. SECTION 12: GENERAL INDEMNIFICATION - In the event that, as a result of this Agreement, or actions taken as required hereunder, the Village is made a party defendant in any litigation arising by reason of this Agreement, and development activities contemplated hereunder, the owners agree to defend and hold harmless the Village, the mayor, trustees, officers and agents thereof, individually and collectively, from any suits and from any claims, demands, setoff or other action including but not limited to judgments arising therefrom. The obligation of the owners hereunder shall include and extend to payment of reasonable attorneys' fees for the representation of the Village and its said officers and agents in such litigation and includes expenses, court costs and fees; it being understood that the owners where there shall be no applicable standards provided therein, shall have the right to employ all such attorneys to represent the Village and its officers and agents in such litigation, subject to the approval of the corporate authorities of the Village, which approval shall not be unreasonably withheld. The owners shall have the right to appeal to courts of 6 appellate jurisdiction any judgment taken against the Village or its officers or agents in this respect, and the Village shall join in any such appeal taken by the owners. SECTION 13: PERFORMANCE OF AGREEMENT - It is agreed that the parties hereto may in law or in equity, by suit, action, mandamus, or any other proceeding, including specific performance, enforce or compel the performance of this Agreement, which shall include the right of the parties to recover a judgment for monetary damages against each other, provided, however, that the owners shall not have a right to recover a judgment for monetary damages against any elected or appointed official of the Village for any breach of any of the terms of this Agreement. The Village reserves the right to maintain an action to recover damages or any sums which owners have agreed to pay pursuant to this Agreement and which have become due and remained unpaid. SECTION 14: EXHIBITS - It is agreed that Exhibits I through VII shall be considered part of this agreement. SECTION 15: DISPLAY OF VILLAGE FUNDING PROMOTIONAL MATERIAL All program participants shall be required to prominently display a poster identifying the property as receiving Village funding. The sign will be provided by the Village and shall be displayed from the date the Application is approved, to no less than thirty (30) days after final approval and reimbursement is made. SECTION 16: GUARANTEE OF FUNDS - The filing of an application for Building and Site Improvement Grant in no way is a guarantee of funding by the Village of Lemont. 7 IN WITNESS THEREOF, the parties hereto have executed this Agreement on the date first appearing above. OWNERS/LESSEE Program Participant Date: (O- " 9 ci ■ Property Owner Date: -C� Form Rev. 7/99 8 Village Presiden Date: - ti %�Z EXHIBIT I EXHIBITS PROOF OF OWNERSHIP IN FORM OF DEED OR TITLE INSURANCE POLICY (TAX BILL IS NOT ACCEPTABLE). VWffENITYMMAEYMWSO PIONIMPOWNESNIMIGNS illiMPINWPIENOP EXHIBIT III COPY OF APPLICATION E 1[k- EXHIBIT V CONTRACTOR'S AGREEMENT PRIMPIPPIP EXHIBIT VII IsioNNIMINRIMMIROMMTI SAMPLE LIEN SIGNED AND NOTORIZED. 9 C' ".CAGO TITLE INSURANCE Cur 'AiN 1 LOAN POLICY (1992) SCHEDULE A DATE OF POLICY: AUGUST 19, 1996 AMOUNT OF INSURANCE: YOUR LOAN REFERENCE: LIM 1. NAME OF INSURED: LEMONT NATIONAL BANK EXHIBIT I POLICY NO.: 1410 007605737 OF $87,000.00 LOAN NUMBER: 2. THE ESTATE OR INTEREST IN THE LAND DESCRIBED IN THIS SCHEDULE AND WHICH IS ENCUMBERED BY THE INSURED MORTGAGE OR TRUST DEED IS A FEE SIMPLE, UNLESS OTHERWISE NOTED. 3. TITLE TO THE ESTATE OR INTEREST IN THE LAND IS VESTED IN: JUNG YUNG LIM AND NAM SOON LIM, HIS WIFE, AS JOINT TENANTS 4. THE INSURED MORTGAGE OR TRUST DEED, AND ASSIGNMENTS THEREOF, IF ANY, ARE DESCRIBED AS FOLLOWS: MORTGAGE DATED APRIL 30, SOON 24, NATCIONAL BANK TO MADE BY JUNG YUNG LIM A NOTE FOR $87,000.00. THIS POLICY VALID ONLY IF SCHEDULE B IS ATTACHED. LPOt M92 VB1 12/02/96 14:44:23 C `CAGO TITLE INSURANCE CO.' AN LOAN POLICY (1992) SCHEDULE A (CONTINUED) POLICY NO.: 1410 007605737 OF 5, THE LAND REFERRED TO IN THIS POLICY IS DESCRIBED AS FOLLOWS: PARCEL 1: LOT 15 IN BLOCK 3 IN VILLAGE OF LEMONT, A SUBDIVISION IN THE SOUTH FRACTION OF THE SOUTHWEST 1/4 OF SECTION 20, TOWNSHIP 37 NORTH, RANGE 11 EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS PARCEL 2: LOT 16 IN BLOCK 3 IN THE VILLAGE OF LEMONT, A SUBDIVISION IN THE SOUTH FRACTION OF THE SOUTHWEST 1/4 OF SECTION 20, TOWNSHIP 37 NORTH, RANGE 11 EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS THIS POLICY VALID ONLY IF SCHEDULE B IS ATTACHED. LPOLA 2 VB1 12/02/96 14:44:24 C CAGU "ITILb I1VJUKAINL I LU: rul 1 LOAN POLICY (1992) SCHEDULE B POLICY NO.: 1410 007605737 OF NOTWITHSTANDING THE PROVISIONS OF THE CONDITIONS AND STIPULATIONS OF THIS POLICY, ALL ENDORSEMENTS, IF ANY, ATTACHED HERETO ARE VALID DESPITE SECRETARY, THE ETARYK OF SIGNATURE BY EITHER THE PRESIDENT, A VICE PRESIDENT, THE ASSISTANT SECRETARY, OR VALIDATING OFFICER OR AUTHORIZED SIGNATORY OF THE COMPANY. THIS POLICY DOES NOT INSURE AGAINST LOSS OR DAMAGE SUSTAINED BY THE INSURED (AND THE COMPANY WILL NOT PAY COSTS, ATTORNEY'S FEES OR EXPENSES) WHICH ARISE BY REASON OF: SPECIAL EXCEPTIONS: L 1. TAXES FOR THE YEAR 1996. 1996 TAXES ARE NOT YET DUE OR PAYABLE. PERMANENT INDEX NUMBER: 22 -20 -312- 004 -0000 1 OF 2. NOTE: 1995 FIRST ESTIMATED INSTALLMENT AMOUNTING TO $1,315.69 IS PAID. NOTE: 1995 FINAL INSTALLMENT AMOUNTING TO $1,289.63 IS PAID. * * * * * TAXES FOR THE YEAR 1996. 1996 TAXES ARE NOT YET DUE OR PAYABLE. PERMANENT INDEX NUMBER: 22 -20- 312 - 005 -0000 2 OF 2. NOTE: 1995 FIRST ESTIMATED INSTALLMENT AMOUNTING TO $1,918.73 IS PAID. NOTE: 1995 FINAL INSTALLMENT AMOUNTING TO $1,880.64 IS PAID. LPBI t92 VB1 12/02/96 14:44:26 r IICAGO TITLE 1N S U KAN C:1: LA. ran I POLICY SIGNATURE PAGE ORDER NO.: 1410 007605737 OF THIS POLICY SHALL NOT BE VALID OR BINDING UNTIL SIGNED BY AN AUTHORIZED SIGNATORY. CHICAGO TITLE INSURANCE COMPANY BY f AU'T'HORIZED SIGNATORY PO[SIGPO VB1 12/02/96 14:44:27 ENDORSEMENT ATTACHED TO AND FORMING A PART � OF POLICY NUMBER ISSUED BY CHICAGO TITLE INSURANCE COMPANY LOCATION ENDORSEMENT 1 THE COMPANY HEREBY INSURES THE INSURED AGAINST LOSS OR DAMAGE WHICH THE INSURED SHALL SUSTAIN BY REASON OF ANY INACCURACIES IN THE FOLLOWING ASSURANCES: 1. THAT, ACCORDING TO PLAT OF SUBDIVISION, THE LAND DESCRIBED IN SCHEDULE A HAS STREET FRONTAGE OF 44 FEET, AND A DEPTH OF 132 FEET, AND IS LOCATED 88 FEET NORTHEASTERLY OF STATE STREET ON THE SOUTHEASTERLY LINE OF MAIN STREET; 2. THAT THERE IS LOCATED ON SAID LAND A COMMERCIAL BUILDING; AND 3. THAT THE BUILDING ON SAID LAND HAS NUMBER 208 AND 210 THEREON, INDICATING THAT THE SAME IS KNOWN AS 208 AND 210 MAIN STREET, LEMONT, COOK COUNTY, ILLINOIS. THIS ENDORSEMENT IS MADE A PART OF THE POLICY AND IS SUBJECT TO ALL OF THE TERMS AND PROVISIONS THEREOF AND OF ANY PRIOR ENDORSEMENTS THERETO. EXCEPT TO THE EXTENT EXPRESSLY STATED, IT NEITHER MODIFIES ANY OF THE TERMS AND PROVISIONS OF THE POLICY AND ANY PRIOR ENDORSEMENTS, NOR DOES IT EXTEND THE EFFECTIVE DATE OF THE POLICY AND ANY PRIOR ENDORSEMENTS, NOR DOES IT INCREASE THE FACE AMOUNT THEREOF. ENDIPG VB1 ENDORSEMENT ATTACHED TO AND FORMING A PART OF POLICY NUMBER 1410 007605737 OF ISSUED BY CHICAGO TITLE INSURANCE COMPANY COMPREHENSIVE ENDORSEMENT 1 THE COMPANY HEREBY INSURES THE INSURED AGAINST LOSS OR DAMAGE WHICH THE INSURED SHALL SUSTAIN BY REASON OF: 1. ANY INACCURACIES IN THE FOLLOWING ASSURANCES: (A) THAT THERE ARE NO COVENANTS, CONDITIONS OR RESTRICTIONS UNDER WHICH THE LIEN OF THE MORTGAGE REFERRED TO IN SCHEDULE A CAN BE DIVESTED OR SUBORDINATED OR ITS VALIDITY, PRIORITY OR ENFORCEABILITY OTHERWISE IMPAIRED; (B) THAT, UNLESS OTHERWISE EXPRESSLY SET FORTH OR INDICATED TO THE CONTRARY IN SCHEDULE B: (1) THERE ARE NO PRESENT VIOLATIONS ON SAID LAND OF ANY ENFORCEABLE COVENANTS, CONDITIONS OR RESTRICTIONS OR PLAT BUILDING LINES; (2) ANY INSTRUMENT REFERRED TO IN SCHEDULE B AS SPECIFICALLY CONTAINING "COVENANTS AND RESTRICTIONS" AFFECTING SAID LAND DOES NOT, IN ADDITION, ESTABLISH AN EASEMENT THEREON OR PROVIDE FOR EITHER A LIEN FOR LIQUIDATED DAMAGES, A LEVY OF A PRIVATE CHARGE OR ASSESSMENT, AN OPTION TO PURCHASE, OR THE PRIOR APPROVAL OF A FUTURE PURCHASER OR OCCUPANT; (3) THERE ARE NO ENCROACHMENTS OF EXISTING IMPROVEMENTS LOCATED ON SAID LAND ONTO ADJOINING LAND, NOR ANY ENCROACHMENTS ONTO SAID LAND OF EXISTING IMPROVEMENTS LOCATED ON ADJOINING LAND; (4) THERE ARE NO ENCROACHMENTS OF EXISTING IMPROVEMENTS LOCATED ON SAID LAND ONTO THE PORTION OF SAID LAND SUBJECT TO ANY EASEMENT SHOWN IN SCHEDULE B. 2. ANY FUTURE VIOLATIONS ON SAID LAND OF ANY COVENANTS, CONDITIONS OR RESTRICTIONS OCCURRING PRIOR TO THE ACQUISITION OF TITLE TO SAID LAND BY THE INSURED, PROVIDED SUCH VIOLATIONS RESULT IN LOSS OF THE LIEN OF THE MORTGAGE REFERRED TO IN SCHEDULE A OR IMPAIR THE VALIDITY, PRIORITY OR ENFORCEABILITY OF SUCH LIEN, OR RESULT IN LOSS OF THE TITLE TO SAID ESTATE OR INTEREST IF THE INSURED SHALL ACQUIRE TITLE IN SATISFACTION OF THE INDEBTEDNESS SECURED BY SUCH MORTGAGE. 3. THE ENTRY OF ANY COURT ORDER OR JUDGMENT WHICH CONSTITUTES A FINAL DETERMINATION AND DENIES THE RIGHT TO MAINTAIN ANY EXISTING IMPROVEMENTS ON SAID LAND BECAUSE OF ANY VIOLATION OF ANY COVENANTS, CONDITIONS OR RESTRICTIONS OR PLAT BUILDING LINES OR BECAUSE OF ANY ENCROACHMENT THEREOF OVER ONTO ADJOINING LAND. WHEREVER IN THIS ENDORSEMENT ANY OR ALL THE WORDS APPEAR, THEY SHALL NOT BE DEEMED TO REFER TO OR TO CONDITIONS, OR LIMITATIONS CONTAINED IN ANY LEASE, DECLARATION OF CONDOMINIUM REFERRED TO IN SCHEDULE "COVENANTS, CONDITIONS OR RESTRICTIONS" INCLUDE THE TERMS, COVENANTS, INSTRUMENT CREATING AN EASEMENT OR A. THIS ENDORSEMENT IS MADE A PART OF THE POLICY AND IS SUBJECT TO ALL OF THE TERMS AND PROVISIONS THEREOF AND OF ANY PRIOR ENDORSEMENTS THERETO. EXCEPT TO THE EXTENT EXPRESSLY STATED, IT NEITHER MODIFIES ANY OF THE TERMS AND PROVISIONS OF THE POLICY AND ANY ENDORSEMENTS, NOR DOES IT EXTEND THE EFFECTIVE DATE OF THE POLICY AND ANY PRIOR ENDORSEMENTS, NOR DOES IT INCREASE THE FACE AMOUNT THEREOF. ENDIPG VB1 ENDORSEMENT ATTACHED TO POLICY NUMBER D14 OR 007605737 �OF OF ISSUED BY CHICAGO TITLE INSURANCE COMPANY ALTA ENDORSEMENT FORM 9.1 THE INSURANCE AFFORDED BY THIS ENDORSEMENT IS ONLY EFFECTIVE IF THE LAND IS USED OR IS TO BE USED PRIMARILY FOR RESIDENTIAL PURPOSES. THE COMPANY INSURES THE INSURED AGAINST LOSS OR DAMAGE SUSTAINED BY REASON OF LACK OF PRIORITY OF THE LIEN OF THE INSURED MORTGAGE OVER: 1. ANY ENVIRONMENTAL PROTECTION LIEN WHICH, AT DATE OF POLICY, IS RECORDED IN THOSE RECORDS ESTABLISHED UNDER STATE STATUTES AT DATE OF POLICY FOR THE PURPOSES OF IMPARTING CONSTRUCTIVE NOTICE OF MATTERS RELATING TO REAL PROPERTY TO PURCHASERS FOR VALUE AND WITHOUT KNOWLEDGE, OR FILED IN THE RECORDS OF THE CLERK OF THE UNITED STATES DISTRICT COURT FOR THE DISTRICT IN WHICH THE LAND IS LOCATED, EXCEPT AS SET FORTH IN SCHEDULE B; OR 2. ANY ENVIRONMENTAL PROTECTION LIEN PROVIDED FOR BY ANY STATE STATUTE IN EFFECT AT DATE OF POLICY, EXCEPT ENVIRONMENTAL PROTECTION LIENS PROVIDED FOR BY THE FOLLOWING STATE STATUTES: NONE. THIS ENDORSEMENT IS MADE A PART OF THE POLICY AND IS SUBJECT TO ALL OF THE TERMS AND PROVISIONS THEREOF AND OF ANY PRIOR ENDORSEMENTS THERETO. EXCEPT TO THE EXTENT EXPRESSLY STATED, IT NEITHER MODIFIES ANY OF THE TERMS AND PROVISIONS OF THE POLICY AND ANY PRIOR ENDORSEMENTS, NOR DOES IT EXTEND THE EFFECTIVE DATE OF THE POLICY AND ANY PRIOR ENDORSEMENTS, NOR DOES IT INCREASE THE FACE AMOUNT THEREOF. ENDIPG VB 1 PAYMENT taut 11/01/1999 Payment Due 11/01/1999 2,098.48 UC I AVf VVUr't9 ADV V C 1117LJ nC 1 Un17 1111n 1 VUn rrt, 11yu6sv 1 1998 Cook County Real Estate Tax Bill Amount Paid Permanent Real Estate Index Number Volume How much is due and when? If payment received or postmarked by: Payment due is: 22 -20- 312 - 005 -0000 * *Put this number on check made payabl &to Cook County Collector. 062 Pro 210 MAIN ST LEMONT IL 60439 Tax Code Year Township 19012 1998 LEMONT Unpaid 1st Installment s Installmel?t-'2n nstallment 2nd Installment (due 3/11999) Penalty due 1111999 Penalty 10/01/99 11/01/99 2,098.48 11/02/99 12/01/99 2,129.96 Where do the dollars go? 0.00 0.00 2,098.48 0.00 0.00 0.00 2,098.48 31.48 Amt. paid 1st installment: 2,319.94 ON 02 -17-99 Thank you. By state law, late payment penalty is 1.5% per month. Taxing District 1998 Tax 98 Rate 1998 Pension 1997 Tax 97 Rate SCHOOL DISTRICT C.0 N0.113 BOND 13.64 0.027 161.80 0.325 COMBINED SCHOOL DISTRICT C.C. NO. 113A 1,088.32 2.155 232.81 1,179.88 2.370 TIF VIL OF LEMONT- DOWNTOWN 0.00 0.000 0.00 0.000 LEMONT FIRE PROTECTION DISTRICT 442.90 0.877 37.87 423.66 0.851 LEMONT PUBLIC LIBRARY DIST 112.11 0.222 6.56 110.52 0.222 VILLAGE OF LEMONT 405.53 0.803 95.44 412.71 0.829 LEMONT PARK DISTRICT 199.99 0.396 19.69 201.63 0.405 JOLIEi COMMUNITY COLLEGE DISTRICT 525 109.08 0.216 2.02 108.03 0.217 LEMONT TOWNSHIP HIGH SCHOOL 210 1,175.69 2.328 27.77 1,161.46 2.333 SOUTH COOK COUNTY MOSQ ABATEMENT DIST 6.57 0.013 5.97 0.012 METRO WATER RECLAMATION DIST OF GR CHGO 224.23 0.444 14.64 224.53 0.451 GENERAL ASSISTANCE LEMONT 1.52 0.003 1.49 0.003 ROAD AND BRIDGE LEMONT 77.27 0.153 76.17 0.153 TOWN LEMONT 61.11 0.121 60.24 0.121 CONSOLIDATED ELECTIONS 0.00 0.000 13.44 0.027 SUBURBAN T B SANITARIUM 4.04 0.008 3.98 0.008 FOREST PRESERVE DISTRICT OF COOK COUNTY 36.36 0.072 1.51 36.84 0.074 COUNTY OF COOK 339.87 0.673 85.34 315.64 0.634 COOK COUNTY HEALTH FACILITIES 120.19 0.238 141.88 0.285 ' TOTAL (DO NOT PAY THESE AMOUNTS) • 4,418.42 8.749 4,639.87 9.320 4707/350 _ _ _ Oct 7, 1999 ...06 AO 3:04 a P T N- PPI PD 72203120050000 70ct99 T! 0 • PCL3 -18 rong see back side): 423 Payment information transcribed from warrant records on file in office of the County Collector. How was my tax calculated? ASSESSED VALUE 23,167 STATE EQUALIZATION FACTOR X 2.1799 EQUALIZED ASSESSED VALUE 50,502 TAX RATE % X 8.749% 1998 TAX (BEFORE EXEMPTIONS) = 4,418.42 HOMEOWNERS EXEMPTION 0.00 SENIOR CITIZEN EXEMPTION 0.00 SENIOR ASSESSMENT FREEZE 0.00 1996 TAX (AFTER EXEMPTIONS) = 4,418.42 1ST INSTALLMENT 3/01/1999 2,319.94 2ND INSTALLMENT 11/01/1999 { 2,098.48 TOTAL 1998 TAX = 4,418.42 1ST INSTALLMENT PAID 2,319.94 1ST INSTALLMENT LATE PENALTY + 0.00 PAYMENT DUE 11/01/1999 = 2,098.48 Applicant Name: File Number: VILLAGE OF LEMONY BUILDING & SITE IMPROVEMENT GRANT PROGRAM NON -TIF EXHIBIT III APPLICATION Project Address(es): 02/0 41/1/A) i ee e Building Owner: Sun 0- y. Lierl Year Purchased: /9 /7 9 Store /Company Name: Lem 0 n+ Ho it se Ifs -ea A.y- Q'n ' Name of Tenant: Lease Expiration Date: Applicant Name: Tuner Z- �.kr Y +' r Applicant Business Address: 1 D rim /A sit Applicant Business Phone: .6l-R8 0 Home Phone: Ac /7- ( /2 - 6g Applicant(s): Building Owner: 14,1 y. 1. Tenant: Number of Store Fronts: 1 Total Anticipated Budget: $ 01.1 a14 Total Anticipated Grant Request: $ t� O 112- Description of Proposed Improvements:* Bo rn a-re o-P¢ &aril * Attach elevations of proposed improvements (if available) Applicant Name: i File Numu_ r. . Applicant Name: File Number: BUDGET (anticipated) ACTIVITY I ESTIMATED COST I CO/n4-041 h Q4et I frhU2 al 0 4-‘ 1 11950 r OD I 27 r I4 I a70.00 .v? ".ov I Q ke/knerv.e. 6t Q� /j Total Anticipated Grant Request: $ �OK2i Oe Architect for the Project: -SAS , s �C .c'% 6,e Gl%. Tor?'i,c leCh'c45o 7 L 60639 -o -lilO' Name: Address: Phone: Contractor for the Project: Name: SO441.1- Address: Phone: Application will be reviewed by the Economic Development Coordinator , Building Department, and Community Development Director. Applicant Name: File Number: hereby make application to the Village of Lemont for a Building & Site Improv ment Grant Program in the anticipated amount of ,I z4) V. I understand that my application must be approved by the Village and that it must conform to established design guidelines, as well as, specific design recommendations of the Village of Lemont. I have read a copy of the Building & Site Improvement Grant Program Agreement and lien provisions. If approved, I understand that all work performed is subject to development, building, permit, and agreement provisions. /C - 2ff -9' cant Signature Date Please return the completed application to: Economic Development Coordinator Village of Lemont 418 Main Street Lemont, IL 60439 If you need assistance with the application and/or have general inquiries, please contact the Economic Development Coordinator at (630) 257 -6440. EXHIBIT V SRS Inc. Manufacturer & Suppliers of Security Rolling Shutters, Sunscreens Overhead Doors, Grilles, Awnings: Canvas- Retractable -Ba �s Agreement Name [2e ackm en f Lenz Oh d ., 2IJrw� � .S 2. 0) fla ► n 5f Address i # yZ Lemon-I- IL. bO937 Ci State Zip Code (�(,3o 251 — (ZL3 mellow PG es Area - Number Area- Number Sour Ati .-e+Ier trj in Whi k �J Secure Rolling Shutters, Inc. agrees to fumish all materials and labor necessary to complete the following installation at the above location. (,iJee.s Approx. Install Date olor: Box/FraY-Itq1 e 1.090 Ked 4 Rils/Fabry I Color: SlatsNalence /Braiding Q�v�a�► l &vc.S b Color: Control hi 1( �rG E d i Additional Accessories Location:: Projection Panels s Unit Cost /650 Control Cost 1,65') 21 Ircl t!a i c�ak t -3- Additional Information: ram I. Sp i `}l" • / �i� 2' O00tt1 l I L��✓{ . WARRANTY: 5 Vf War 1af, Par is W FabrtL 1 Yr. ftiarrapt Lat7o 1lrs-alla *: 0 'TERMS: 50% Deposit — Balance Due Upon Delivery ACCEPTED: The above prices specifications and conditions are satisfactory and are hereby accepted. SRS is authorized to do this work as specified. Payment will be made as outlined above. Material and custom installation warranted for one lull year all work to be completed in a workmanlike manner and job to be cleaned up and debris hauled away. BUYER BUYER Subtotal Tax: Total Cost. Installation: Grand Total- Deposit. Balance Due Upon Completion. 2f 2(1 2,1 214 25 DATE 7� / /1s r i? Secure Rolling Shutters, Inc. Representative 5700 W. Bloomingdale • Chicago, IL 60639 Phone: (773) 237 -0454 • (1 -800) 920 -9110 • Fax: (773) 237 -0863 • Website: http: / /www.securerollingshutters.com (OVER) WHITE (office copy) * YELLOW (customer copy) * PINK (file copy) * GOLDEN ROD (production copy) EXHIBIT VII AGREEMENT CREATING LIEN ON REAL ESTATE The undersigned, _ /- /.� , owner(s) of 0710 MAW S 4 , Lemont, Illinois, having applied for Building & Site Improvement Grant Program from the Village of Lemont through General Financing does hereby grant a lien to the Village of Lemont, a Municipal Corporation, in the amount of 644 -D - , 0 Dollars ($ (. &' 2 ) on the property commonly known as �l ! /11R /n) 5 free f , Lemont, Illinois P P Y Y 60439, and legally described as follows: Parcel 2 • Lot 16 n o t Village o Lemont, a subdivision in the south traction or ' ne 7 1/4 of section 20, Township 37 North, Range 11 East of the Third Principal Meridian, in Cook County, Illinois. Parcel 1: Lot 15, Block 3 in the Village of Lemont, a subdivision in the south fraction of the SW 1/4 of section 20, Township 37 N, Range 11 of the Third Principal Meridian, in Cook County, Illinois. Permanent Index Number: p7e2 — 3 12 cos- ©o ® o The undersigned acknowledges that the aforesaid lien shall exist from the date of this instrument, and shall become due if any facade alterations occur less than three years after grant work completion. If this condition occurs, then the lien shall be payable to the Village of Lemont. If this condition does not occur, then the lien shall be removed. The undersigned grants to the Village of Lemont the right to assign, transfer or set over to any other municipal corporation or any part thereof all of the right, title and interest in and to said lien without reservations. DATED this day of , 1998. Form Rev. 4/99 STATE OF ILLINOIS } } SS: COUNTY OF COOK } I, the undersigned, a Not Public in d for County, in the State aforesaid, DO HEREBY CERTIFY that Lt Ltd l vYl is known to me to be the same person(s) Aose e(S) is/are subscribed to the foregoing instrument, appeared before me this day in person, and acknowledged that he /she /they signed, sealed, and delivered the said instrument as a free and voluntary act for the uses and purposes therein set forth. "OFFICIAL SEAL" COLLEEN D. O'HARA Notary Nublic, State of Illinois My Commission Expires August 30, 2003 . 4%'►1. 44 44 44*a4 4. 4.444N4N144 This instrument was prepared by: VILLAGE OF LEMONT 418 Main Street Lemont, Illinois 60439 (630) 257 -6440 Notary Public