R-45-01 Approving village participation in tif building and site grant program for 111 stephen streetVILLAGE OF LEM NT
RESOLUTION NO. /- -/ - (� /
DATE -,z3 .o
RESOLUTION APPROVING VILLAGE PARTICIPATION IN TIF BUILDING
AND SITE GRANT PROGRAM FOR 111 STEPHEN STREET
WHEREAS, the Village of Lemont has adopted Ordinance 0- 71 -99, the Downtown
Building & Site Improvement Grant, Sign Grant and Low Interest Loan Programs, to
provide incentives for building reinvestment within the Village of Lemont's Tax Increment
Financing District; and
WHEREAS, in accordance with the Downtown Building & Site Improvement Grant, the
Village Board of Trustees shall consider participation in building reinvestment; and
WHEREAS, Melan- Elaine -Tom Laketa as the property owner for the property known
111 Stephen Street has completed the Downtown Building & Site Improvement Grant
application for Village participation of said property; and
WHEREAS, Village Staff has reviewed the 111 Stephen Street application for
compliance with the Downtown Building & Site Improvement Grant guidelines and has
recommended approval of the request.
NOW, THEREFORE, BE IT RESOLVED, that the Village President is authorized to
execute the Building and Site Grant Agreement attached for One Thousand Seven
Hundred and Seventy -Five Dollars ($1,775.00) in accordance with the terms of the
Downtown Building & Site Improvement guidelines.
PASSED AND APPROVED BY THE PRESIDENT AND BOARD OF TRUSTEES
OF THE VILLAGE OF LEMONT, COUNTIES OF COOK, DuPAGE AND WILL,
ILLINOIS, on this ,A32dday of ti , 2001.
John Benik
Debby Blatzer
Peter Coules
Connie Markiewicz
Steven Rosendahl
Jeanette Virgilio
AYES NAYS PASSED ABSENT
U
V
v
Approved by me this b2) day of
Attest:
CHARLENE SMOLLEN, Village Clerk
, 2001.
CHARLENE SMOLLEN, Village Clerk
APPROVED AS TO FORM:
Village Attorney
VILLAGE OF LEMONT
BUILDING AND SITE IMPROVEMENT GRANT PROGRAM
AGREEMENT
TIF DISTRICT
THIS AGREEMENT, entered into this day of
, between the
Village of Lemont, Illinois (hereinafter referred to as the "Village ") and the following
designated OWNER/LESSEE, to wit:
Owner's/Lessee's Name: 0%/284' , f L Aa 76; 11
Address: G ,f . E ,e /!4' -
City: ,g,".1 /fit! eRee e State: )1_. Zip Code: ‘G= C
Name of Business:
Project Address(es) /1 / / f l' H5 S /
WITNESSETH
Whereas, the VILLAGE has established a Building & Site Improvement Grant Program for
application within certain designated commercial rehabilitation areas of the VILLAGE
known as the Tax Increment Financing District; and
Whereas, said Building & Site Improvement Grant Program is administered by the
VILLAGE and is funded from District Revenues for purposes of control and prevention of
blight, dilapidation and deterioration of designated areas within the District, and
Whereas, pursuant to said Program the VILLAGE has agreed to participate, subject to its
sole discretion. in sharing the cost of Building & Site Improvements to commercial
establishments within the District up to a maximum of one -half (l /2) of the approved
contract cost of such improvement but in no event shall the total Village participation
exceed Ten Thousand Dollars Seven Hundred Fifty Dollars ($10,750.00) for construction
and architectural cost with $750.00 of that amount reserved for sign improvements only.
Architectural fees shall be limited to a One Thousand Dollars ($1,000.00) reimbursement;
and
Whereas, the OWNER's/LESSEE's property is located within the Tax Increment
Financing District/Downtown, a designated rehabilitation area, and the OWNER/LESSEE
desires to participate in the Building and Site Improvement Grant Program pursuant to the
terms and provisions of this agreement.
NOW, THEREFORE, in consideration of the mutual covenants and agreement obtained
herein, the VILLAGE and OWNER/LESSEE do hereby agree as follows:
SECTION 1: COST SHARING - The VILLAGE shall share in the building and site
improvement cost and architect fee cost for the OWNER's/LESSEE's property up to fifty
percent (50 %), up to a maximum amount not exceeding Ten Thousand Seven Hundred
Fifty Dollars ($10,750.00) for construction and architectural cost with $750.00 reserved
for sign improvements. Architectural reimbursement shall be One Thousand Dollars
($1,000.00) . The actual amount per this agreement shall not exceed $ for
construction cost and $ for architect fees. The building and site improvement
/historic preservation costs which are eligible for VILLAGE participation include all labor,
materials, equipment and other contract items necessary for the proper execution and
completion of the work as designated from the design drawings approved by the
VILLAGE. Said design drawings and specifications are attached hereto as Exhibit IV.
2
SECTION 2: DESIGN APPROVAL - No building and site improvement or historic
preservation work shall be undertaken until the design therefore has been submitted to and
approved by the Village. Following approval, the OWNER/LESSEE shall contract for the
work and shall commence and complete all such work within one hundred eighty (180) days
from the date of such approval.
SECTION 3: REVIEW OF PROJECT - The Economic Development Coordinator shall
periodically review the progress of the contractor's work on the building and site
improvement and historic preservation pursuant to this Agreement. Such inspections shall
not replace any required permit inspection by Village Inspectors. All work which is not in
conformance with the approved drawings and specifications shall be immediately remedied
by the OWNER/LESSEE and deficient or improper work shall be replaced and made to
comply with the approved drawings, specifications, and terms of this Agreement.
SECTION 4: DOCUMENTATION REQUIREMENTS - Upon completion of the
building and site improvement/historic preservation and upon its final inspection and
approval by the Building Department, the OWNER/LESSEE shall submit to the VILLAGE
a properly executed and notarized contractor statement and architect fee statement showing
the full cost of the work as well as each separate component amount due to the contractor
and each and every subcontractor involved in furnishing labor, materials, or equipment in
the work. In addition, the OWNER/LESSEE shall submit to the VILLAGE proof of
payment of the contract cost pursuant to the contractor's and architect's statements. The
VILLAGE shall, within thirty (30) days of receipt of the contractor's statement and proof
of payment issue a check to the OWNER/LESSEE in payment of: one -half of the approved
cost or Ten Thousand Seven Hundred Fifty Dollars ($10,750.00) whichever is less. In no
case shall the amount paid to the OWNER/LESSEE exceed the amount specified in this
Agreement or in the contractor's or architect's statements. At the time of reimbursement
3
and throughout the term of this agreement, the land use and signage under the control of
the OWNER/LESSEE shall be in conformance with zoning and sign code provisions.
SECTION 5: FAILURE TO COMPLETE WORK - If the OWNER/LESSEE or his
contractor fail to complete the building and site improvement/historic preservation work
provided for herein in conformity with the plans, specifications and all terms of this
Agreement, the Agreement shall terminate and the financial obligation on the part of the
VILLAGE shall cease and become null and void.
SECTION 6: ELIGIBLE IMPROVEMENT WORK - Installation, repair and
replacement of exit doors and hardware; repair, replacement or addition of exterior shutters
and awnings /canopies; repair and replacement or installation of exterior stairs, porches,
railings and exit facilities; repair and rebuilding of exterior walls, including cleaning, sealing,
tuck pointing and painting; repair of window frames, sills, glazing, replacement of glass and
installation of new windows; installation of landscaping which meets Downtown
Streetscape Master Plan; asphalt paving for existing gravel parking lots, (does not apply to
new development parking lots or expansion of existing parking lots); replacing or upgrading
of stormwater, curbing, replacement of retaining walls, electrical wiring upgrades, interior
sprinkler systems, fire alarm systems, elevators, interior floor, ceiling improvements,
plumbing and improvements to meet ADA requirements.
SECTION 7: FILING OF LIEN/MAINTENANCE OF IMPROVEMENT - Upon
completion of the building and site improvement work pursuant to this Agreement and for a
period of three (3) years thereafter, the OWNER/LESSEE shall be responsible for properly
maintaining such building and site improvement/historic preservation in its finished form and
without change or alteration thereto, as provided in this Agreement, and for the said period
of three (3) years following completion of the construction thereof, the OWNER/LESSEE
shall not enter into any Agreement or contract or take any other steps to alter, change or
4
remove such improvement, or the approved design thereof, nor shall OWNER/LESSEE
undertake any other changes, by contract or otherwise, to the improvement provided for in
this Agreement unless such changes are first submitted to the Economic Development
Coordinator, and any additional review body or commission for approval; which approval
shall not be unreasonably withheld if the proposed changes do not substantially alter the
original design concept of the building and site improvements as specified in the drawings
and plans approved pursuant to this Agreement. In addition to this section, a lien on the
OWNER/LESSEE property shall be filed prior to the final payout of the program
reimbursement.
SECTION 8: UNRELATED IMPROVEMENTS - Nothing herein is intended to limit,
restrict or prohibit the OWNER/LESSEE from undertaking any other work in or about the
subject premises which is unrelated to the building and site improvement provided for in this
Agreement.
SECTION 9: AGREEMENT APPLICABLE TO FUTURE OWNERS - This
Agreement shall be binding upon the VILLAGE OF LEMONT and upon the
OWNER/LESSEE and its successors, to said property for a period of three (3) years from
and after the date of completion and approval of the facade improvement provided for
herein. It shall be the responsibility of the OWNER/LESSEE to inform subsequent
OWNER(s)/LESSEE(s) of Section 7 of this Agreement.
SECTION 10: MAXIMUM GRANT AWARDS - Nothing in this Agreement shall
prohibit a business or property owner from applying for more than one Grant. However, a
Ten Thousand Seven Hundred Fifty Dollars ($10,750.00) total limitation shall apply to all
Sign Grants, Building and Site Grants or Interest Rate Program Awards made to a single
building and/or lot within any three (3) year period. For the purpose of calculating the three
(3) year period, the date of the last Village payment shall be considered the start of the three
5
(3) year period. No grant may be utilized for the same or similar building contract work,
within a ten (10) year period of the last Village payment.
SECTION 11: VILLAGE INDEMNIFICATION REGARDING CONSTRUCTION
The owners of the subject property agree to defend and hold harmless the Village from any
and all claims which may arise out of said owners' construction activities under this
Agreement.
SECTION 12: GENERAL INDEMNIFICATION - In the event that, as a result of this
Agreement, or actions taken as required hereunder, the Village is made a party defendant in
any litigation arising by reason of this Agreement, and development activities contemplated
hereunder, the owners agree to defend and hold harmless the Village, the mayor, trustees,
officers and agents thereof, individually and collectively, from any suits and from any
claims, demands, setoff or other action including but not limited to judgments arising
therefrom. The obligation of the owners hereunder shall include and extend to payment of
reasonable attorneys' fees for the representation of the Village and its said officers and
agents in such litigation and includes expenses, court costs and fees; it being understood
that the owners where there shall be no applicable standards provided therein, shall have the
right to employ all such attorneys to represent the Village and its officers and agents in such
litigation, subject to the approval of the corporate authorities of the Village, which approval
shall not be unreasonably withheld. The owners shall have the right to appeal to courts of
appellate jurisdiction any judgment taken against the Village or its officers or agents in this
respect, and the Village shall join in any such appeal taken by the owners.
SECTION 13: PERFORMANCE OF AGREEMENT - It is agreed that the parties
hereto may in law or in equity, by suit, action, mandamus, or any other proceeding,
including specific performance, enforce or compel the performance of this Agreement,
6
which shall include the right of the parties to recover a judgment for monetary damages
against each other, provided, however, that the owners shall not have a right to recover a
judgment for monetary damages against any elected or appointed official of the Village for
any breach of any of the terms of this Agreement. The Village reserves the right to maintain
an action to recover damages or any sums which owners have agreed to pay pursuant to
this Agreement and which have become due and remained unpaid.
SECTION 14: EXHIBITS - It is agreed that Exhibits I through VII shall be considered
part of this agreement.
SECTION 15: DISPLAY OF VILLAGE FUNDING PROMOTIONAL MATERIAL
All program participants shall be required to prominently display a poster identifying the
property as receiving Village funding. The sign will be provided by the Village and shall be
displayed from the date the Application is approved, to no less than thirty (30) days after
final approval and reimbursement is made.
SECTION 16: GUARANTEE OF FUNDS - The filing of an application for Building and
Site Improvement Grant in no way is a guarantee of funding by the Village of Lemont.
7
IN WITNESS THEREOF, the parties hereto have executed this Agreement on the date
first appearing above.
OWNERS/LESSEE VILLAGE S LEMONT
Program Participant
Date: Date: r I
Property Owner
Date:
Form Rev. 3/00
8
ATTEST:
Village Clerk
Date: 1-A3 -o/
EXHIBIT I
EXHIBIT II
EXHIBITS
PROOF OF OWNERSHIP IN FORM OF DEED OR
TITLE INSURANCE POLICY (TAX BILL IS NOT
ACCEPTABLE).
IF LEASING THE PROPERTY, AN EXECUTED
LEASE IS REQUIRED. ALSO A COPY OF
PROOF OF OWNERSHIP FROM THE BUILDING
OWNER IN THE FORM OF A DEED OR TITLE
INSURANCE POLICY.
EXHIBIT III COPY OF APPLICATION
EXHIBIT IV RENOVATION PLANS
EXHIBIT V CONTRACTOR'S AGREEMENT
EXHIBIT VI ARCHITECT'S AGREEMENT
EXHIBIT VII SAMPLE LIEN SIGNED AND NOTORIZED.
9
",.....Lar—W—N, Icl
AMERICAN LAND TITLE ASSOCIATION
OWNER'S POLICY
(10- 17 -92)
CHICAGO TITLE INSURANCE COMPANY
SUBJECT TO THE EXCLUSIONS FROM COVERAGE, THE EXCEPTIONS FROM COVERAGE
CONTAINED IN SCHEDULE B AND THE CONDITIONS AND STIPULATIONS, CHICAGO TITLE
INSURANCE COMPANY, a Missouri corporation, herein called the Company, insures, as of Date of Policy shown
in Schedule A, against loss or damage, not exceeding the Amount of Insurance stated in Schedule A, sustained or
incurred by the insured by reason of:
1. Title to the estate or interest described in Schedule A being vested other than as stated therein;
2. Any defect in or lien or encumbrance on the title;
3. Unmarketability of the title;
4. Lack of a right of access to and from the land.
The Company will also pay the costs, attorneys' fees and expenses incurred in defense of the title, as insured, but
only to the extent provided in the Conditions and Stipulations.
In Witness Whereof, CHICAGO TITLE INSURANCE COMPANY has caused this policy to be signed and sealed as
of Date of Policy shown in Schedule A, the policy to become valid when countersigned by an authorized signatory.
CHICAGO TITLE INSURANCE COMPANY
By:
By:
VeA0)"4-4.411)i
Secretary
IT=
ALTA Owner's Policy (10- 17 -92)
CHICAGO TITLE INSURANCE COMPANY
OWNER'S POLICY (1992)
SCHEDULE A
POLICY NO.: 1401 007767227 D2
DATE OF POLICY: NOVEMBER 4, 1998
AMOUNT OF INSURANCE: $200,000.00
1. NAME OF INSURED:
MILAN LAKETA AND ELAINE LAKETA, HIS WIFE, AS JOINT TENANTS, AS TO AN UNDIVIDED 1/4
CONTINUED ON NEXT PAGE
2. THE ESTATE OR INTEREST IN THE LAND AND WHICH IS COVERED BY THIS POLICY IS A
FEE SIMPLE, UNLESS OTHERWISE NOTED.
3. TITLE TO SAID ESTATE OR INTEREST AT THE DATE HEREOF IS VESTED IN:
THE INSURED.
4. THE LAND HEREIN DESCRIBED IS ENCUMBERED BY THE FOLLOWING MORTGAGE OR TRUST DEED
AND ASSIGNMENTS:
NONE
AND THE MORTGAGES OR TRUST DEEDS, IF ANY, SHOWN IN SCHEDULE B HEREOF.
THIS POLICY VALID ONLY IF SCHEDULE B IS ATTACHED.
OPOLA192
CB3 08/05/99 11:54:58
CHICAGO TITLE INSURANCE COMPANY
OWNER'S POLICY (1992)
SCHEDULE A (CONTINUED)
POLICY NO.: 1401 007767227 D2
INTEREST, AS TO PARCEL 1;
MILAN LAKETA AND ELAINE LAKETA, HUSBAND AND WIFE, AS TENANTS IN COMMON, AS TO AN
UNDIVIDED 1/4 INTEREST, AS TO PARCEL 1;
THOMAS LAKETA, A WIDOWER NOT SINCE REMARRIED, AS TO AN UNDIVIDED 2/4, AS TO PARCEL
1.
MILAN LAKETA AND ELAINE LAKETA, HIS WIFE, AS JOINT TENANTS, AS TO AN UNDIVIDED 1/4
INTEREST, AS TO PARCEL 2;
MILAN LAKETA AND ELAINE LAKETA, HUSBAND AND WIFE, AS TENANTS IN COMMON, AS TO AN
UNDIVIDED 1/4 INTEREST, AS TO PARCEL 2;
THOMAS LAKETA, A WIDOWER NOT SINCE REMARRIED, AS TO AN UNDIVIDED 2/4 INTEREST, AS TO
PARCEL 2.
THIS POLICY VALID ONLY IF SCHEDULE B IS ATTACHED.
OPOLA292
CB3 08/05/99 11:54:58
CHICAGO TITLE INSURANCE COMPANY
OWNER'S POLICY (1992)
SCHEDULE A (CONTINUED)
POLICY NO.: 1401 007767227
D2
5. THE LAND REFERRED TO IN THIS POLICY IS DESCRIBED AS FOLLOWS:
PARCEL 1:
THAT PART OF LOTS 1 AND 2 IN BLOCK 28 IN KEEPOTAW, A SUBDIVISION IN SECTION 20,
TOWNSHIP 37 NORTH, RANGE 11, EAST OF THE THIRD PRINCIPAL MERIDIAN, DESCRIBED AS
FOLLOWS: BEGINNING AT A POINT IN THE SOUTH LINE OF LOT 1 AFORESAID 9.70 FEET WEST
OF THE SOUTHEAST CORNER OF SAID LOT 1, THENCE NORTH 22 DEGREES WEST 39 FEET 6 -3/5
INCHES, THENCE SOUTH 68 DEGREES WEST 60 FEET, THENCE SOUTH 22 DEGREES EAST 14
FEET 4 -1/8 INCHES TO THE SOUTH LINE OF SAID LOT 2, AND THENCE EAST ALONG THE
SOUTH LINE OF LOTS 2 AND 1 AFORESAID TO THENCE POINT OF BEGINNING, IN COOK
COUNTY, ILLINOIS.
PARCEL 2:
LOT 1 IN BLOCK 1 IN SINGER AND TALCOTT'S FIRST ADDITION TO LEMONT, A SUBDIVISION
IN THE WEST 1/2 OF THE SOUTH EAST 1/4 OF SECTION 20, TOWNSHIP 37 NORTH, RANGE 11,
EAST OF THE THIRD PRINCIPAL MERIDIAN, IN COOK COUNTY, ILLINOIS
THIS POLICY VALID ONLY IF SCHEDULE H IS ATTACHED
OPtwls92
CB3 08/05/99 11:54:58
CHICAGO TITLE INSURANCE COMPANY
OWNER'S POLICY (1992)
SCHEDULE B
POLICY NO.: 1401 007767227 02
NOTWITHSTANDING THE PROVISIONS OF THE CONDITIONS AND STIPULATIONS OF THIS
POLICY, ALL ENDORSEMENTS, IF ANY, ATTACHED HERETO ARE VALID DESPITE THE LACK OF
SIGNATURE BY EITHER THE PRESIDENT, A VICE PRESIDENT, THE SECRETARY, AN
ASSISTANT SECRETARY, OR VALIDATING OFFICER OR AUTHORIZED SIGNATORY OF THE
COMPANY.
EXCEPTIONS FROM COVERAGE
THIS POLICY DOES NOT INSURE AGAINST LOSS OR DAMAGE SUSTAINED BY THE INSURED
(AND THE COMPANY WILL NOT PAY COSTS, ATTORNEY'S FEES OR EXPENSES) BY REASON OF
THE FOLLOWING EXCEPTIONS:
GENERAL EXCEPTIONS:
(1) RIGHTS OR CLAIMS OF PARTIES IN POSSESSION NOT SHOWN BY PUBLIC RECORDS.
(2) ENCROACHMENTS, OVERLAPS, BOUNDARY LINE DISPUTES, OR OTHER MATTERS WHICH
WOULD BE DISCLOSED BY AN ACCURATE SURVEY AND INSPECTION OF THE PREMISES.
(3) EASEMENTS, OR CLAIMS OF EASEMENTS, NOT SHOWN BY THE PUBLIC RECORDS.
(4) ANY LIEN, OR RIGHT TO A LIEN, FOR SERVICES, LABOR OR MATERIAL HERETOFORE
OR HEREAFTER FURNISHED, IMPOSED BY LAW AND NOT SHOWN BY THE PUBLIC
RECORDS.
(5) TAXES OR SPECIAL ASSESSMENTS WHICH ARE NOT SHOWN AS EXISTING LIENS BY THE
PUBLIC RECORDS.
SPECIAL EXCEPTIONS: THE MORTGAGE, IF ANY, REFERRED TO IN ITEM 4 OF SCHEDULE A
6.
1. TAXES FOR THE YEARS) 1998
1998 TAXES ARE NOT YET DUE OR PAYABLE.
LA. NOTE: 1997 FIRST INSTALLMENT WAS DUE
NOTE: 1997 FINAL INSTALLMENT WAS DUE
PERM TAX#
22 -20- 404 - 003 -0000
22 -20- 406 - 001 -0000
PCL
1 OF 2
2 OF 2
YEAR 1ST INST
1997 $2,016.33
1997 $2,008.21
MARCH 03, 1998
OCTOBER 28, 1998
STAT
PAID
PAID
2ND INST
$2,119.79
$2,111.32
STAT
PAID
PAID
7. AGREEMENT CREATING LIEN ON THE LAND BY MILAN, ELAINE AND TOM LAKETA FOR
FACADE IMPROVEMENT IN FAVOR OF THE VILLAGE OF LEMONT IN THE AMOUNT OF
$3,349.50, RECORDED SEPTEMBER 4, 1998 AS DOCUMENT NUMBER 98792375.
(AFFECTS PARCEL 2)
C 8. THE BUILDING LOCATED PRINCIPALLY ON LAND IS APPARENTLY OVER AND UPN THE
STREET NORTHEASTERLY OF LAND APPROXIMATELY 3 FEET 4 INCHES.
(AFFECTS PARCEL 1)
OPOLB192
CB3 08/05/99 11:55:00
CHICAGO TITLE INSURANCE COMPANY
OWNER'S POLICY (1992)
SCHEDULE B
POLICY NO.:
1401
007767227 02
EXCEPTIONS FROM COVERAGE
(CONTINUED)
0 9. THE SOUTHEAST CORNER OF THE BUILDING LOCATED PRINCIPALLY UPON LAND IS OVER
AND UPON THE PREMISES SOUTH AND ADJOINING LAND APPROXIMATELY 1 FOOT 9
INCHES.
(AFFECTS PARCEL 1)
E 10. THE BUILDING LOCATED PRINCIPALLY UPON THE PREMISES SOUTH AND ADJOINING LAND
IS OVER AND UPON THE SOUTHEASTERLY CORNER OF LAND APPROXIMATELY 10 INCHES.
(AFFECTS PARCEL 1)
S 11. EXISTING UNRECORDED MONTH TO MONTH LEASES AND ALL RIGHTS THEREUNDER OF THE
LESSEES AND OF ANY PERSON OR PARTY CLAIMING BY, THROUGH OR UNDER THE
LESSEES, AS DISCLOSED BY ALTA STATEMENT.
OPOLE=
CB3 08/05/99 11:55:00
CHICAGO TITLE INSURANCE COMPANY
POLICY SIGNATURE PAGE
POLICY No.: 1401 007767227 02
THIS POLICY SHALL NOT BE VALID OR BINDING UNTIL SIGNED BY AN AUTHORIZED SIGNATORY.
CHICAGO TITLE INSURANCE COMPANY
BY
AUTHO D SIGNATOR
POLSIGPG
CB3 08/05/99 11:55:00
Applicant Name:
File Number:
VILLAGE OF LEMONT
BUILDING & SITE IMPROVEMENT
GRANT PROGRAM
TIF DISTRICT
APPLICATION
Project Address(es): /'/ ; S 7 E Pi, t- 4/ S r
Building Owner:4) /4,6/ ;, - r� icvti'r -7241 A A E -r ,4 Year Purchased: /7,,> S
Store /Company Name:
Name of Tenant: Lease Expiration Date:
Applicant Name: /}2 / iht/ — Ei Ai A/ 7' j'i i ,L »A' 774
Applicant Business Address: /1/ 5t-e pkfe Sr -
Applicant Business Phone: . 1 v5- Home Phone: y_s 9- e
Applicant(s): Building Owner: s fr flJ Tenant:
Number of Store Fronts:
Total Anticipated Budget:
Total Anticipated Grant Request:
$ 3, SSr
$ 0075
Description of Proposed Improvements:*
(H- PO/Ai % g0140/#4/6-
* Attach elevations of proposed improvements (if available)
PICTURE OF STORE FRONT:
Applicant Name:
File Number:
Applicant Name:
File Number:
BUDGET
(anticipated)
ACTIVITY
ESTIMATED COST
7--c,/,; fel 7' K.,-
3 5-'36, (i
9
Total Anticipated Grant Request: $
Architect for the Project:
Name:
Address:
Phone:
S.1, 77,5 co
Contractor for the Project:
Name:
Address:
Phone:
Application will be reviewed by the Economic Development Coordinator , Building
Department, and Community Development Director.
Applicant Name:
File Number:
I, /2 6-A) - L /iii ✓r - /c ,it A. ht, t(by make application to the Village of Lemont for
a Building & Site Improvement Grant Program in the anticipated amount of
$ /7 g57 . I understand that my application must be approved by the
Village and that it must conform to established design guidelines, as well as, specific design
recommendations of the Village of Lemont. I have read a copy of the Building & Site
Improvement Grant Program Agreement and lien provisions. If approved, I understand that
all work performed is subject to development, building, permit, and agreement provisions.
1/14
g/9. 0
Applicant Signature Date
SfrI2L /4S ,4I '
Building Owner
Please return the completed application to:
Economic Development Coordinator
Village of Lemont
418 Main Street
Lemont, IL 60439
Date
g/9-11/ e
If you need assistance with the application and/or have general inquiries, please contact the
Economic Development Coordinator at (630) 257 -6440.
JZ TUCKPOINTING (708) 788 -0732
1433 GROVE, BERWYN IL. 60402
Proposal Submitted To
Name Toff
Street 111 sr EPHEN S.ZFET
City LEMONr
State Illinois
Phone Number (63o) 734 - SOo S
Work To Be Performed At
Street /1/ SrEpf#Enl Sra2EEr
City LEHUNr
State Illinois
Phone Number (6Jo) 739 — 300
We hereby propose to furnish all the materials and perform all the labor necessary for the completion of
I uCKPO lit/ TiNG OP THE F20NT (L/Esr) [.BALL .
TaC+e7 o,NT I %✓G OP THE A/o7Z714 (s DE) 1.341-4, .
2EKOu4L OF LCosE 11ozr#4 -2? c3/1 E A/6E D E D .
Calculated price for the materials and labor is $ 3,sso.0Q
* * * * * 7," mg, Tilous,4A/ r, FILE Ar.A., ',RZ> F4 ry * * * ** Dollars
Any alteration or deviation from above specifications involving extra costs, will be executed only upon written orders, and will become an
extra charge over and above the estimate. All agreements contingent upon strikes, accidents or delays beyond our control. Owner to carry fire,
tornado and other necessary insurance upon above work. Workmen's Compensation and Public Liability Insurance on above work to be taken
out by State Security Insurance Company
Respectfully submitted de
Accepted
Date r/ /3 /2001
Date / /
SAMPLE
AGREEMENT CREATING LIEN ON REAL ESTATE
The undersigned, %YI/L 4 V.- C1ccrh. — , owner(s) of
/1/ 31 //2/1/ $ C 7 , Lemont, Illinois, having applied for
Building & Site Improvement Grant Program from the Village of Lemont through TIF
Financing District does hereby grant a lien to the Village of Lemont, a Municipal v�
Corporation, in the amount of - MoKS4vG Se ve 1 hit edv Jl Se -e y=1Dollars
($ 1,7752—°) on the property commonly known as 1/1 S/veel
Lemont, Illinois 60439, and legally described as follows:
1v¢ /
8 810c-k- S � J k e p k c i c L 4-1 L".""1/ K 5 040nN t 3 l`• "2 01 4 f t n , Et- V.. 5 h o n o
"1-0,„A&S11 e 31 Jv.-.4i
"Clot p 1L , C-rt4 rf k"( 111°4,- f r vl c FCC I M .f' GC l R VN
Permanent Index Number: 2 Z - 20 '" 4-06 0G — CCU O
The undersigned acknowledges that the aforesaid lien shall exist from the date of
this instrument, and shall become due if any facade alterations occur less than three years
after grant work completion. If this condition occurs, then the lien shall be payable to the
Village of Lemont. If this condition does not occur, then the lien shall be removed.
The undersigned grants to the Village of Lemont the right to assign, transfer or set
over to any other municipal corporation or any part thereof all of the right, title and interest
in and to said lien without reservations.
DATED this
Form Rev. 2/00
day of